BEGIN:VCALENDAR VERSION:2.0 PRODID:-//wp-events-plugin.com//7.2.2.1//EN BEGIN:VEVENT UID:1@jbcc.co.za DTSTART;TZID=Africa/Johannesburg:20230215T130000 DTEND;TZID=Africa/Johannesburg:20230216T160000 DTSTAMP:20230209T060208Z URL:https://jbcc.co.za/events/jbcc-agreements-contracts-2018-2020-feb-2023 / SUMMARY:JBCC AGREEMENTS / CONTRACTS 2018 / 2020 – Feb 2023 DESCRIPTION:This is a training course conducted online using zoom presented in two sessions starting from 13h00 and ends at 16h00\nPresented by  – Rakesh Singh\n\nSESSION 1\n\n Construction Law\n Pre-Contract Activitie s\n Risk Management Procurement / Contract Data\n Dispute Resolution\nMe diation\nAdjudication\nArbitration\n Definitions\n Offer and Acceptance Documents\n Agents/ Design Duties of the Parties\n Subcontractors\n\n\nS ESSION 2\n\n Contract Instructions\n Execution &\; Completion Penalti es (Damages)\n Payments\n Adjustment of the Contract Value\n Insurances &\; Securities\n Suspension &\; Termination\n Differences between editions 4.1\, 6. 1 and 6.2\n State Contract Data\n New Contracts (SSWC &\; DCC)\n\n\nVIRTUAL SEMINAR COST (FOR BOTH SESSIONS): \nSingle dele gate  |  R3 575.00\nMultiple delegates (2 or more)  |  R3 300.00\n \nSession 1:Feb 15\, 2023 01:00 PM Session 2:Feb 16\, 2023 01:00 PM\n\nTi me shows in Johannesburg\n\n\nEARN CPD CREDITS!  TOTAL OF 7 HOURS\n(Eac h session: 3 hours and 1 hour for quiz completion)\n*PLEASE NOTE: Registe r with the email address that you will use to access the webinar on the da y of the sessions.*\n/*! elementor - v3.10.2 - 29-01-2023 */.elementor-col umn .elementor-spacer-inner{height:var(--spacer-size)}.e-con{--container-w idget-width:100%}.e-con-inner>.elementor-widget-spacer\,.e-con>.elementor- widget-spacer{width:var(--container-widget-width\,var(--spacer-size))\;--a lign-self:var(--container-widget-align-self\,initial)\;--flex-shrink:0}.e- con-inner>.elementor-widget-spacer>.elementor-widget-container\,.e-con-inn er>.elementor-widget-spacer>.elementor-widget-container>.elementor-spacer\ ,.e-con>.elementor-widget-spacer>.elementor-widget-container\,.e-con>.elem entor-widget-spacer>.elementor-widget-container>.elementor-spacer{height:1 00%}.e-con-inner>.elementor-widget-spacer>.elementor-widget-container>.ele mentor-spacer>.elementor-spacer-inner\,.e-con>.elementor-widget-spacer>.el ementor-widget-container>.elementor-spacer>.elementor-spacer-inner{height: var(--container-widget-height\,var(--spacer-size))}\n\n\nREGISTER HERE\n ATTACH;FMTTYPE=image/jpeg:https://jbcc.co.za/wp-content/uploads/2019/01/se rvices-3-960x600-1.jpeg END:VEVENT BEGIN:VEVENT UID:2@jbcc.co.za DTSTART;TZID=Africa/Johannesburg:20230322T130000 DTEND;TZID=Africa/Johannesburg:20230323T160000 DTSTAMP:20230201T110701Z URL:https://jbcc.co.za/events/jbcc-agreements-contracts-2018-2020-march-20 23/ SUMMARY:JBCC AGREEMENTS / CONTRACTS 2018/ 2020 - March 2023 DESCRIPTION:This is a training course conducted online using zoom presented in two sessions starting from 13h00 and ends at 16h00\nPresented by  – Rakesh Singh\nSESSION 1\n\n Construction Law\n Pre-Contract Activities\ n Risk Management Procurement / Contract Data\n Dispute Resolution\nMedi ation\nAdjudication\nArbitration\n Definitions\n Offer and Acceptance Do cuments\n Agents/ Design Duties of the Parties\n Subcontractors\n\n\nSES SION 2\n\n Contract Instructions\n Execution &\; Completion Penalties (Damages)\n Payments\n Adjustment of the Contract Value\n Insurances & amp\; Securities\n Suspension &\; Termination\n Differences between e ditions 4.1\, 6. 1 and 6.2\n State Contract Data\n New Contracts (SSWC & amp\; DCC)\n\nVIRTUAL SEMINAR COST (FOR BOTH SESSIONS): \nSingle delegate   |  R3 575.00\nMultiple delegates (2 or more)  |  R3 300.00\n\nSe ssion 1:March 22\, 2023 01:00 PM Session 2:March 23\, 2023 01:00 PM\n\nTi me shows in Johannesburg\n\nEARN CPD CREDITS!  TOTAL OF 7 HOURS\n(Each session: 3 hours and 1 hour for quiz completion)\n*PLEASE NOTE: Register with the email address that you will use to access the webinar on the day of the sessions.*\n/*! elementor - v3.10.2 - 29-01-2023 */\n.elementor-col umn .elementor-spacer-inner{height:var(--spacer-size)}.e-con{--container-w idget-width:100%}.e-con-inner>.elementor-widget-spacer\,.e-con>.elementor- widget-spacer{width:var(--container-widget-width\,var(--spacer-size))\;--a lign-self:var(--container-widget-align-self\,initial)\;--flex-shrink:0}.e- con-inner>.elementor-widget-spacer>.elementor-widget-container\,.e-con-inn er>.elementor-widget-spacer>.elementor-widget-container>.elementor-spacer\ ,.e-con>.elementor-widget-spacer>.elementor-widget-container\,.e-con>.elem entor-widget-spacer>.elementor-widget-container>.elementor-spacer{height:1 00%}.e-con-inner>.elementor-widget-spacer>.elementor-widget-container>.ele mentor-spacer>.elementor-spacer-inner\,.e-con>.elementor-widget-spacer>.el ementor-widget-container>.elementor-spacer>.elementor-spacer-inner{height: var(--container-widget-height\,var(--spacer-size))}\n\n\nREGISTER HERE\n ATTACH;FMTTYPE=image/jpeg:https://jbcc.co.za/wp-content/uploads/2019/01/se rvices-3-960x600-1.jpeg END:VEVENT BEGIN:VEVENT UID:8@jbcc.co.za DTSTART;TZID=Africa/Johannesburg:20230503T130000 DTEND;TZID=Africa/Johannesburg:20230504T160000 DTSTAMP:20230421T092321Z URL:https://jbcc.co.za/events/jbcc-agreements-contracts-2018-2020-4-5-may- 2023/ SUMMARY:JBCC AGREEMENTS/CONTRACTS 2018/2020 - 4/5 May 2023 DESCRIPTION:This is a training course conducted online using zoom presented in two sessions starting from 13h00 and ends at 16h00Presented by – Pro fessor Maritz \n /*! elementor - v3.10.2 - 29-01-2023 */\n.elementor-wi dget-divider{--divider-border-style:none\;--divider-border-width:1px\;--di vider-color:#2c2c2c\;--divider-icon-size:20px\;--divider-element-spacing:1 0px\;--divider-pattern-height:24px\;--divider-pattern-size:20px\;--divider -pattern-url:none\;--divider-pattern-repeat:repeat-x}.elementor-widget-div ider .elementor-divider{display:flex}.elementor-widget-divider .elementor- divider__text{font-size:15px\;line-height:1\;max-width:95%}.elementor-widg et-divider .elementor-divider__element{margin:0 var(--divider-element-spac ing)\;flex-shrink:0}.elementor-widget-divider .elementor-icon{font-size:va r(--divider-icon-size)}.elementor-widget-divider .elementor-divider-separa tor{display:flex\;margin:0\;direction:ltr}.elementor-widget-divider--view- line_icon .elementor-divider-separator\,.elementor-widget-divider--view-li ne_text .elementor-divider-separator{align-items:center}.elementor-widget- divider--view-line_icon .elementor-divider-separator:after\,.elementor-wid get-divider--view-line_icon .elementor-divider-separator:before\,.elemento r-widget-divider--view-line_text .elementor-divider-separator:after\,.elem entor-widget-divider--view-line_text .elementor-divider-separator:before{d isplay:block\;content:""\;border-bottom:0\;flex-grow:1\;border-top:var(--d ivider-border-width) var(--divider-border-style) var(--divider-color)}.ele mentor-widget-divider--element-align-left .elementor-divider .elementor-di vider-separator>.elementor-divider__svg:first-of-type{flex-grow:0\;flex-sh rink:100}.elementor-widget-divider--element-align-left .elementor-divider- separator:before{content:none}.elementor-widget-divider--element-align-lef t .elementor-divider__element{margin-left:0}.elementor-widget-divider--ele ment-align-right .elementor-divider .elementor-divider-separator>.elemento r-divider__svg:last-of-type{flex-grow:0\;flex-shrink:100}.elementor-widget -divider--element-align-right .elementor-divider-separator:after{content:n one}.elementor-widget-divider--element-align-right .elementor-divider__ele ment{margin-right:0}.elementor-widget-divider:not(.elementor-widget-divide r--view-line_text):not(.elementor-widget-divider--view-line_icon) .element or-divider-separator{border-top:var(--divider-border-width) var(--divider- border-style) var(--divider-color)}.elementor-widget-divider--separator-ty pe-pattern{--divider-border-style:none}.elementor-widget-divider--separato r-type-pattern.elementor-widget-divider--view-line .elementor-divider-sepa rator\,.elementor-widget-divider--separator-type-pattern:not(.elementor-wi dget-divider--view-line) .elementor-divider-separator:after\,.elementor-wi dget-divider--separator-type-pattern:not(.elementor-widget-divider--view-l ine) .elementor-divider-separator:before\,.elementor-widget-divider--separ ator-type-pattern:not([class*=elementor-widget-divider--view]) .elementor- divider-separator{width:100%\;min-height:var(--divider-pattern-height)\;-w ebkit-mask-size:var(--divider-pattern-size) 100%\;mask-size:var(--divider- pattern-size) 100%\;-webkit-mask-repeat:var(--divider-pattern-repeat)\;mas k-repeat:var(--divider-pattern-repeat)\;background-color:var(--divider-col or)\;-webkit-mask-image:var(--divider-pattern-url)\;mask-image:var(--divid er-pattern-url)}.elementor-widget-divider--no-spacing{--divider-pattern-si ze:auto}.elementor-widget-divider--bg-round{--divider-pattern-repeat:round }.rtl .elementor-widget-divider .elementor-divider__text{direction:rtl}.e- con-inner>.elementor-widget-divider\,.e-con>.elementor-widget-divider{widt h:var(--container-widget-width)\;--flex-grow:var(--container-widget-flex-g row)} \n Prof Maritz’s involvement in standard form construction contr acts started in 1993 when co-opted on the JBCC Technical Committee and was until recently intimately involved in the drafting process of the various editions published to date. His involvement includes the complete overhau l of the latest 6th Edition to bring it in line with modern international contracts such as the FIDIC\, NEC\, JCT\, AS4000 and others.After retiring from an academic career of more than 42 years at the University of Pretor ia he was appointed as the CEO of the JBCC for a two-year contract period and his involvement in JBCC matters expanded to include the presentation o f training seminars (public and in-house)\, providing contractual informat ion via a Q&\;A service and the publication of Advisory Notes\, etc.\, on JBCC’s website. His contract appointment expired on 1 March 2021His i nvolvement in model documentation for the construction industry also spans over many years. He was appointed on the Standard System Joint Committee in 1988 and was involved in the publication of various SMM Editions\, the latest being the SMM 7th in 2015. Under his chairmanship a committee       drafted and published the Model Bills of Quantities (widely used by a ll quantity surveying practices in South Africa) as well as the Model Bill s of Quantities  for Small and Simple Buildings. He has been the author a nd co-author of a number of handbooks for the profession\, the latest bein g the book entitled  JBCC 2020 and all that – A practical interpretatio n\, 2nd EditionHe acts regularly as either and adjudicator\, arbitrator\, mediator or expert witness in alternative dispute resolution matters in th e South African construction industry \n SESSION 1Construction LawPre-Co ntract ActivitiesRisk Management Procurement / Contract DataDispute Resolu tionMediation   Adjudication   ArbitrationDefinitions Offer and Accep tance DocumentsAgents/ Design Duties of the Parties Subcontractors SESSI ON 2Contract Instructions Execution &\; Completion Penalties (Damages)  Payments Adjustment of the Contract Value Insurances &\; Securities Suspension &\; TerminationDifferences between editions 4.1\, 6. 1 and 6 .2State Contract DataNew Contracts (SSWC &\; DCC) VIRTUAL SEMINAR COST (FOR BOTH SESSIONS): Single delegate  |  R3 575.00Multiple delegates (2 or more)  |  R3 300.00Session 1:May 3\, 2023 01:00 PM Session 2:M ay 4\, 2023 01:00 PMTime shows in JohannesburgEARN CPD CREDITS!  TOTAL OF 7 HOURS(Each session: 3 hours and 1 hour for quiz completion)*PLEASE NO TE: Register with the email address that you will use to access the webin ar on the day of the sessions.* \n /*! elementor - v3.10.2 - 29-01-2023 */\n.elementor-column .elementor-spacer-inner{height:var(--spacer-size)}. e-con{--container-widget-width:100%}.e-con-inner>.elementor-widget-spacer\ ,.e-con>.elementor-widget-spacer{width:var(--container-widget-width\,var(- -spacer-size))\;--align-self:var(--container-widget-align-self\,initial)\; --flex-shrink:0}.e-con-inner>.elementor-widget-spacer>.elementor-widget-co ntainer\,.e-con-inner>.elementor-widget-spacer>.elementor-widget-container >.elementor-spacer\,.e-con>.elementor-widget-spacer>.elementor-widget-cont ainer\,.e-con>.elementor-widget-spacer>.elementor-widget-container>.elemen tor-spacer{height:100%}.e-con-inner>.elementor-widget-spacer>.elementor-wi dget-container>.elementor-spacer>.elementor-spacer-inner\,.e-con>.elemento r-widget-spacer>.elementor-widget-container>.elementor-spacer>.elementor-s pacer-inner{height:var(--container-widget-height\,var(--spacer-size))} \n \n REGISTER HERE\n ATTACH;FMTTYPE=image/jpeg:https://jbcc.co.za/wp-content/uploads/2019/01/se rvices-3-960x600-1.jpeg END:VEVENT BEGIN:VEVENT UID:9@jbcc.co.za DTSTART;TZID=Africa/Johannesburg:20230516T130000 DTEND;TZID=Africa/Johannesburg:20230516T160000 DTSTAMP:20230421T101313Z URL:https://jbcc.co.za/events/extension-of-time-and-role-of-the-principal- agent-webinar/ SUMMARY:EXTENSION OF TIME AND ROLE OF THE PRINCIPAL AGENT WEBINAR - 16 May 2023 DESCRIPTION:JBCC MAY 2018 6TH EDITION: CLAUSE 23.0GUIDELINES ON HOW TO ADMI NISTER EXTENSION OF TIME FOR PRACTICAL COMPLETIONPresented by – Professo r Maritz &\; Gerard Damstra \n /*! elementor - v3.10.2 - 29-01-2023 */\n.elementor-widget-divider{--divider-border-style:none\;--divider-borde r-width:1px\;--divider-color:#2c2c2c\;--divider-icon-size:20px\;--divider- element-spacing:10px\;--divider-pattern-height:24px\;--divider-pattern-siz e:20px\;--divider-pattern-url:none\;--divider-pattern-repeat:repeat-x}.ele mentor-widget-divider .elementor-divider{display:flex}.elementor-widget-di vider .elementor-divider__text{font-size:15px\;line-height:1\;max-width:95 %}.elementor-widget-divider .elementor-divider__element{margin:0 var(--div ider-element-spacing)\;flex-shrink:0}.elementor-widget-divider .elementor- icon{font-size:var(--divider-icon-size)}.elementor-widget-divider .element or-divider-separator{display:flex\;margin:0\;direction:ltr}.elementor-widg et-divider--view-line_icon .elementor-divider-separator\,.elementor-widget -divider--view-line_text .elementor-divider-separator{align-items:center}. elementor-widget-divider--view-line_icon .elementor-divider-separator:afte r\,.elementor-widget-divider--view-line_icon .elementor-divider-separator: before\,.elementor-widget-divider--view-line_text .elementor-divider-separ ator:after\,.elementor-widget-divider--view-line_text .elementor-divider-s eparator:before{display:block\;content:""\;border-bottom:0\;flex-grow:1\;b order-top:var(--divider-border-width) var(--divider-border-style) var(--di vider-color)}.elementor-widget-divider--element-align-left .elementor-divi der .elementor-divider-separator>.elementor-divider__svg:first-of-type{fle x-grow:0\;flex-shrink:100}.elementor-widget-divider--element-align-left .e lementor-divider-separator:before{content:none}.elementor-widget-divider-- element-align-left .elementor-divider__element{margin-left:0}.elementor-wi dget-divider--element-align-right .elementor-divider .elementor-divider-se parator>.elementor-divider__svg:last-of-type{flex-grow:0\;flex-shrink:100} .elementor-widget-divider--element-align-right .elementor-divider-separato r:after{content:none}.elementor-widget-divider--element-align-right .eleme ntor-divider__element{margin-right:0}.elementor-widget-divider:not(.elemen tor-widget-divider--view-line_text):not(.elementor-widget-divider--view-li ne_icon) .elementor-divider-separator{border-top:var(--divider-border-widt h) var(--divider-border-style) var(--divider-color)}.elementor-widget-divi der--separator-type-pattern{--divider-border-style:none}.elementor-widget- divider--separator-type-pattern.elementor-widget-divider--view-line .eleme ntor-divider-separator\,.elementor-widget-divider--separator-type-pattern: not(.elementor-widget-divider--view-line) .elementor-divider-separator:aft er\,.elementor-widget-divider--separator-type-pattern:not(.elementor-widge t-divider--view-line) .elementor-divider-separator:before\,.elementor-widg et-divider--separator-type-pattern:not([class*=elementor-widget-divider--v iew]) .elementor-divider-separator{width:100%\;min-height:var(--divider-pa ttern-height)\;-webkit-mask-size:var(--divider-pattern-size) 100%\;mask-si ze:var(--divider-pattern-size) 100%\;-webkit-mask-repeat:var(--divider-pat tern-repeat)\;mask-repeat:var(--divider-pattern-repeat)\;background-color: var(--divider-color)\;-webkit-mask-image:var(--divider-pattern-url)\;mask- image:var(--divider-pattern-url)}.elementor-widget-divider--no-spacing{--d ivider-pattern-size:auto}.elementor-widget-divider--bg-round{--divider-pat tern-repeat:round}.rtl .elementor-widget-divider .elementor-divider__text{ direction:rtl}.e-con-inner>.elementor-widget-divider\,.e-con>.elementor-wi dget-divider{width:var(--container-widget-width)\;--flex-grow:var(--contai ner-widget-flex-grow)} \n SESSION 1JBCC May 2018 6th Edition: Clause 23. 0 Guidelines on How to Administer Extension of Time for Practical Completi on\nPresenter: Professor Maritz \n• Delays where the contractor is not a t fault would normally constitute a valid claim for (EOT). • Delays affe cts critical path of projects. • Confirming a delay and/ or disruption i s not an easy task: it is a time-consuming process\, especially in multifa ceted projects with thousands of activities\, a lot of details\, as well a s the involvement of many stakeholders. • It is important for clients\, contractors\, sub-contractors\, and consultants to understand the fundamen tal requirements of compiling a successful EOT claim\, and the adjudicatio n of claims submitted. • These training notes will provide those involve d in the preparation and adjudication of EOT claims under the JBCC with so me essential information to deal more productively with this complex matte r. • On larger projects\, the magnitude of time-related costs can easily run into millions of rand. With so much at stake\, it is understandable t hat delay claims are a major source of disputes in the construction indust ry. • The proper assessment of delay claims is essential so that the par ties can deal with it without having to resolve the dispute in expensive a nd drawn-out arbitration or litigation processes.\nSESSION 2JBCC MAY 2018 6th Edition: Understanding The Roles of The Various Role Players Involved in The Building Contract with Emphasis on The Role of The Principal Agent\ nPresenter: Gerard Damstra\n• The building contract involves a host of r ole players to establish a successful project - role players all have spec ific functions to be performed within specific boundaries\, with specific powers entrusted to them. • Role players must work together to ensure a successful project is completed within timeframes and with professionalism \, integrity\, honesty and moral standards. • Some functions are regulat ed by contracts between role players\, but others are governed by the stan dards laid down by society – the so-called boni mores of a community. • Role players must be aware of the impact of their actions. • It is i mperative that all parties involved in a project have proper detailed know ledge of their respective roles\, powers\, duties\, timelines and applicat ion of specialised professional contributions to the “team.” • It is the function of the principal agent to bring all the aspects\, required f or a successful building project\, together in a coordinated and orderly m anner. • The role of the principal agent therefore requires a proper und erstanding or else a project may fall apart to the detriment of all partie s involved. • If the role of the principal agent is not fully understood \, chaos may be the result in which all parties suffer financial loss\, im paired reputations and environmental damage. \n VIRTUAL SEMINAR COST :  Single delegate  |  R1 750.00Multiple delegates (2 or more)  |  R1 500.00One day webinar from 13h00 -16h00Time shows in JohannesburgEARN CP D CREDITS!  TOTAL OF 7 HOURS(Each session: 3 hours and 1 hour for quiz c ompletion)*PLEASE NOTE: Register with the email address that you will use to access the webinar on the day of the sessions.* \n /*! elementor - v3.10.2 - 29-01-2023 */\n.elementor-column .elementor-spacer-inner{height: var(--spacer-size)}.e-con{--container-widget-width:100%}.e-con-inner>.elem entor-widget-spacer\,.e-con>.elementor-widget-spacer{width:var(--container -widget-width\,var(--spacer-size))\;--align-self:var(--container-widget-al ign-self\,initial)\;--flex-shrink:0}.e-con-inner>.elementor-widget-spacer> .elementor-widget-container\,.e-con-inner>.elementor-widget-spacer>.elemen tor-widget-container>.elementor-spacer\,.e-con>.elementor-widget-spacer>.e lementor-widget-container\,.e-con>.elementor-widget-spacer>.elementor-widg et-container>.elementor-spacer{height:100%}.e-con-inner>.elementor-widget- spacer>.elementor-widget-container>.elementor-spacer>.elementor-spacer-inn er\,.e-con>.elementor-widget-spacer>.elementor-widget-container>.elementor -spacer>.elementor-spacer-inner{height:var(--container-widget-height\,var( --spacer-size))} \n \n REGISTER HERE\n ATTACH;FMTTYPE=image/jpeg:https://jbcc.co.za/wp-content/uploads/2019/01/se rvices-3-960x600-1.jpeg END:VEVENT BEGIN:VEVENT UID:5@jbcc.co.za DTSTART;TZID=Africa/Johannesburg:20230523T130000 DTEND;TZID=Africa/Johannesburg:20230524T160000 DTSTAMP:20230421T092433Z URL:https://jbcc.co.za/events/jbcc-agreements-contracts-2018-2020-may-2023 / SUMMARY:JBCC AGREEMENTS/CONTRACTS 2018/2020 - May 2023 DESCRIPTION:This is a training course conducted online using zoom presented in two sessions starting from 13h00 and ends at 16h00\nPresented by – P rofessor Maritz\n/*! elementor - v3.10.2 - 29-01-2023 */\n.elementor-widge t-divider{--divider-border-style:none\;--divider-border-width:1px\;--divid er-color:#2c2c2c\;--divider-icon-size:20px\;--divider-element-spacing:10px \;--divider-pattern-height:24px\;--divider-pattern-size:20px\;--divider-pa ttern-url:none\;--divider-pattern-repeat:repeat-x}.elementor-widget-divide r .elementor-divider{display:flex}.elementor-widget-divider .elementor-div ider__text{font-size:15px\;line-height:1\;max-width:95%}.elementor-widget- divider .elementor-divider__element{margin:0 var(--divider-element-spacing )\;flex-shrink:0}.elementor-widget-divider .elementor-icon{font-size:var(- -divider-icon-size)}.elementor-widget-divider .elementor-divider-separator {display:flex\;margin:0\;direction:ltr}.elementor-widget-divider--view-lin e_icon .elementor-divider-separator\,.elementor-widget-divider--view-line_ text .elementor-divider-separator{align-items:center}.elementor-widget-div ider--view-line_icon .elementor-divider-separator:after\,.elementor-widget -divider--view-line_icon .elementor-divider-separator:before\,.elementor-w idget-divider--view-line_text .elementor-divider-separator:after\,.element or-widget-divider--view-line_text .elementor-divider-separator:before{disp lay:block\;content:""\;border-bottom:0\;flex-grow:1\;border-top:var(--divi der-border-width) var(--divider-border-style) var(--divider-color)}.elemen tor-widget-divider--element-align-left .elementor-divider .elementor-divid er-separator>.elementor-divider__svg:first-of-type{flex-grow:0\;flex-shrin k:100}.elementor-widget-divider--element-align-left .elementor-divider-sep arator:before{content:none}.elementor-widget-divider--element-align-left . elementor-divider__element{margin-left:0}.elementor-widget-divider--elemen t-align-right .elementor-divider .elementor-divider-separator>.elementor-d ivider__svg:last-of-type{flex-grow:0\;flex-shrink:100}.elementor-widget-di vider--element-align-right .elementor-divider-separator:after{content:none }.elementor-widget-divider--element-align-right .elementor-divider__elemen t{margin-right:0}.elementor-widget-divider:not(.elementor-widget-divider-- view-line_text):not(.elementor-widget-divider--view-line_icon) .elementor- divider-separator{border-top:var(--divider-border-width) var(--divider-bor der-style) var(--divider-color)}.elementor-widget-divider--separator-type- pattern{--divider-border-style:none}.elementor-widget-divider--separator-t ype-pattern.elementor-widget-divider--view-line .elementor-divider-separat or\,.elementor-widget-divider--separator-type-pattern:not(.elementor-widge t-divider--view-line) .elementor-divider-separator:after\,.elementor-widge t-divider--separator-type-pattern:not(.elementor-widget-divider--view-line ) .elementor-divider-separator:before\,.elementor-widget-divider--separato r-type-pattern:not([class*=elementor-widget-divider--view]) .elementor-div ider-separator{width:100%\;min-height:var(--divider-pattern-height)\;-webk it-mask-size:var(--divider-pattern-size) 100%\;mask-size:var(--divider-pat tern-size) 100%\;-webkit-mask-repeat:var(--divider-pattern-repeat)\;mask-r epeat:var(--divider-pattern-repeat)\;background-color:var(--divider-color) \;-webkit-mask-image:var(--divider-pattern-url)\;mask-image:var(--divider- pattern-url)}.elementor-widget-divider--no-spacing{--divider-pattern-size: auto}.elementor-widget-divider--bg-round{--divider-pattern-repeat:round}.r tl .elementor-widget-divider .elementor-divider__text{direction:rtl}.e-con -inner>.elementor-widget-divider\,.e-con>.elementor-widget-divider{width:v ar(--container-widget-width)\;--flex-grow:var(--container-widget-flex-grow )}\n\nProf Maritz’s involvement in standard form construction contracts started in 1993 when co-opted on the JBCC Technical Committee and was unti l recently intimately involved in the drafting process of the various edit ions published to date. His involvement includes the complete overhaul of the latest 6th Edition to bring it in line with modern international contr acts such as the FIDIC\, NEC\, JCT\, AS4000 and others.\n\nAfter retiring from an academic career of more than 42 years at the University of Pretori a he was appointed as the CEO of the JBCC for a two-year contract period a nd his involvement in JBCC matters expanded to include the presentation of training seminars (public and in-house)\, providing contractual informati on via a Q&\;A service and the publication of Advisory Notes\, etc.\, o n JBCC’s website. His contract appointment expired on 1 March 2021\n\nHi s involvement in model documentation for the construction industry also sp ans over many years. He was appointed on the Standard System Joint Committ ee in 1988 and was involved in the publication of various SMM Editions\, t he latest being the SMM 7th in 2015. Under his chairmanship a committee       drafted and published the Model Bills of Quantities (widely used by all quantity surveying practices in South Africa) as well as the Model Bi lls of Quantities  for Small and Simple Buildings. He has been the author and co-author of a number of handbooks for the profession\, the latest be ing the book entitled  JBCC 2020 and all that – A practical interpretat ion\, 2nd Edition\n\nHe acts regularly as either and adjudicator\, arbitra tor\, mediator or expert witness in alternative dispute resolution matters in the South African construction industry\nSESSION 1\n\n Construction L aw\n Pre-Contract Activities\n Risk Management Procurement / Contract Da ta\n Dispute Resolution\nMediation\nAdjudication\nArbitration\n Definiti ons\n Offer and Acceptance Documents\n Agents/ Design Duties of the Part ies\n Subcontractors\n\n\nSESSION 2\n\n Contract Instructions\n Executi on &\; Completion Penalties (Damages)\n Payments\n Adjustment of the Contract Value\n Insurances &\; Securities\n Suspension &\; Termin ation\n Differences between editions 4.1\, 6. 1 and 6.2\n State Contract Data\n New Contracts (SSWC &\; DCC)\n\n\nVIRTUAL SEMINAR COST (FOR BO TH SESSIONS): \nSingle delegate  |  R3 575.00\nMultiple delegates (2 or more)  |  R3 300.00\n\nSession 1:May 23\, 2023 01:00 PM Session 2: May 24\, 2023 01:00 PM\n\nTime shows in Johannesburg\n\nEARN CPD CREDITS!   TOTAL OF 7 HOURS\n(Each session: 3 hours and 1 hour for quiz completio n)\n*PLEASE NOTE: Register with the email address that you will use to ac cess the webinar on the day of the sessions.*\n/*! elementor - v3.10.2 - 2 9-01-2023 */\n.elementor-column .elementor-spacer-inner{height:var(--space r-size)}.e-con{--container-widget-width:100%}.e-con-inner>.elementor-widge t-spacer\,.e-con>.elementor-widget-spacer{width:var(--container-widget-wid th\,var(--spacer-size))\;--align-self:var(--container-widget-align-self\,i nitial)\;--flex-shrink:0}.e-con-inner>.elementor-widget-spacer>.elementor- widget-container\,.e-con-inner>.elementor-widget-spacer>.elementor-widget- container>.elementor-spacer\,.e-con>.elementor-widget-spacer>.elementor-wi dget-container\,.e-con>.elementor-widget-spacer>.elementor-widget-containe r>.elementor-spacer{height:100%}.e-con-inner>.elementor-widget-spacer>.ele mentor-widget-container>.elementor-spacer>.elementor-spacer-inner\,.e-con> .elementor-widget-spacer>.elementor-widget-container>.elementor-spacer>.el ementor-spacer-inner{height:var(--container-widget-height\,var(--spacer-si ze))}\n\n\nREGISTER HERE\n ATTACH;FMTTYPE=image/jpeg:https://jbcc.co.za/wp-content/uploads/2019/01/se rvices-3-960x600-1.jpeg END:VEVENT BEGIN:VEVENT UID:6@jbcc.co.za DTSTART;TZID=Africa/Johannesburg:20230621T130000 DTEND;TZID=Africa/Johannesburg:20230622T160000 DTSTAMP:20230614T091138Z URL:https://jbcc.co.za/events/jbcc-agreements-contracts-2018-2020-june-202 3/ SUMMARY:JBCC AGREEMENTS/CONTRACTS 2018/2020 - June 2023 DESCRIPTION:This is a training course conducted online using zoom presented in two sessions starting from 13h00 and ends at 16h00Presented by  – P rofessor MaritzObjectives:The interpretation and understanding of the JBCC agreements and contracts is fundamental in carrying out a successful cons truction project to final completion stage. Many projects stand still due the lack of contract knowledge in implementation. It is crucial that contr acting parties adhere and fully understand the JBCC clauses before enterin g a JBCC agreement. This webinar reviews the JBCC clauses from implementat ion of a project to the final completion stages and gives a view to the de legates the challenges that might be experienced in progamme stages\, reme dies that can be used and what to avoid when administering a project using the JBCC agreements.Learning Outcomes:Describe the development of the var ious types of building contracts in use in South Africa\;Identify the impo rtant role of the JBCC documents in the South African building industry\;H ave an in-depth understanding of the historical background and structure o f the JBCC May 2018 6.2nd Ed\;Know what the JBCC documents comprise of and its application in the South African building industry and elsewhere in A frica\;Know what the duties are of the Principal Agent arising from the JB CC documents\; andUnderstand the mechanisms and day-to-day use of a select ion of commonly encountered provisions.SESSION 1Construction LawPre-Contra ct ActivitiesRisk Management Procurement / Contract DataDispute Resolution Mediation   Adjudication   ArbitrationDefinitions Offer and Acceptanc e DocumentsAgents/ Design Duties of the Parties SubcontractorsSESSION 2Co ntract Instructions Execution &\; Completion Penalties (Damages) Paym ents Adjustment of the Contract Value Insurances &\; SecuritiesSuspen sion &\; TerminationDifferences between editions 4.1\, 6. 1 and 6.2Stat e Contract DataNew Contracts (SSWC &\; DCC)Who Can Attend:Principal Age nts and Project Managers                                               ArchitectsQuantity SurveyorsEngineersBuilding Contrac tors and SubcontractorsEmployersBuilding Owners\, DevelopersProcurement Of ficersProject FinanciersLegal AdvisorsVIRTUAL SEMINAR COST (FOR BOTH SESSI ONS): Single delegate  |  R3 575.00Multiple delegates (2 or more)   |  R3 300.00Session 1:June 21\, 2023 01:00 PM Session 2:June 22\, 2023 01:00 PMTime shows in JohannesburgEARN CPD CREDITS!  TOTAL OF 7 HOURS(E ach session: 3 hours and 1 hour for quiz completion)*PLEASE NOTE: Registe r with the email address that you will use to access the webinar on the da y of the sessions.* \n /*! elementor - v3.10.2 - 29-01-2023 */\n.elemen tor-column .elementor-spacer-inner{height:var(--spacer-size)}.e-con{--cont ainer-widget-width:100%}.e-con-inner>.elementor-widget-spacer\,.e-con>.ele mentor-widget-spacer{width:var(--container-widget-width\,var(--spacer-size ))\;--align-self:var(--container-widget-align-self\,initial)\;--flex-shrin k:0}.e-con-inner>.elementor-widget-spacer>.elementor-widget-container\,.e- con-inner>.elementor-widget-spacer>.elementor-widget-container>.elementor- spacer\,.e-con>.elementor-widget-spacer>.elementor-widget-container\,.e-co n>.elementor-widget-spacer>.elementor-widget-container>.elementor-spacer{h eight:100%}.e-con-inner>.elementor-widget-spacer>.elementor-widget-contain er>.elementor-spacer>.elementor-spacer-inner\,.e-con>.elementor-widget-spa cer>.elementor-widget-container>.elementor-spacer>.elementor-spacer-inner{ height:var(--container-widget-height\,var(--spacer-size))} \n \n R EGISTER HERE\n ATTACH;FMTTYPE=image/jpeg:https://jbcc.co.za/wp-content/uploads/2019/01/se rvices-3-960x600-1.jpeg END:VEVENT BEGIN:VEVENT UID:10@jbcc.co.za DTSTART;TZID=Africa/Johannesburg:20230627T130000 DTEND;TZID=Africa/Johannesburg:20230627T160000 DTSTAMP:20230614T125223Z URL:https://jbcc.co.za/events/extension-of-time-and-role-of-the-principal- agent-webinar-27-june-2023/ SUMMARY:EXTENSION OF TIME AND ROLE OF THE PRINCIPAL AGENT WEBINAR - 27 June 2023 DESCRIPTION:GUIDELINES ON HOW TO ADMINISTER EXTENSION OF TIME FOR PRACTICAL COMPLETION -JBCC MAY 2018 6TH EDITION: CLAUSE 23.0Presented by – Profes sor Maritz &\; Gerard Damstra/*! elementor - v3.10.2 - 29-01-2023 */.el ementor-widget-divider{--divider-border-style:none\;--divider-border-width :1px\;--divider-color:#2c2c2c\;--divider-icon-size:20px\;--divider-element -spacing:10px\;--divider-pattern-height:24px\;--divider-pattern-size:20px\ ;--divider-pattern-url:none\;--divider-pattern-repeat:repeat-x}.elementor- widget-divider .elementor-divider{display:flex}.elementor-widget-divider . elementor-divider__text{font-size:15px\;line-height:1\;max-width:95%}.elem entor-widget-divider .elementor-divider__element{margin:0 var(--divider-el ement-spacing)\;flex-shrink:0}.elementor-widget-divider .elementor-icon{fo nt-size:var(--divider-icon-size)}.elementor-widget-divider .elementor-divi der-separator{display:flex\;margin:0\;direction:ltr}.elementor-widget-divi der--view-line_icon .elementor-divider-separator\,.elementor-widget-divide r--view-line_text .elementor-divider-separator{align-items:center}.element or-widget-divider--view-line_icon .elementor-divider-separator:after\,.ele mentor-widget-divider--view-line_icon .elementor-divider-separator:before\ ,.elementor-widget-divider--view-line_text .elementor-divider-separator:af ter\,.elementor-widget-divider--view-line_text .elementor-divider-separato r:before{display:block\;content:""\;border-bottom:0\;flex-grow:1\;border-t op:var(--divider-border-width) var(--divider-border-style) var(--divider-c olor)}.elementor-widget-divider--element-align-left .elementor-divider .el ementor-divider-separator>.elementor-divider__svg:first-of-type{flex-grow: 0\;flex-shrink:100}.elementor-widget-divider--element-align-left .elemento r-divider-separator:before{content:none}.elementor-widget-divider--element -align-left .elementor-divider__element{margin-left:0}.elementor-widget-di vider--element-align-right .elementor-divider .elementor-divider-separator >.elementor-divider__svg:last-of-type{flex-grow:0\;flex-shrink:100}.elemen tor-widget-divider--element-align-right .elementor-divider-separator:after {content:none}.elementor-widget-divider--element-align-right .elementor-di vider__element{margin-right:0}.elementor-widget-divider:not(.elementor-wid get-divider--view-line_text):not(.elementor-widget-divider--view-line_icon ) .elementor-divider-separator{border-top:var(--divider-border-width) var( --divider-border-style) var(--divider-color)}.elementor-widget-divider--se parator-type-pattern{--divider-border-style:none}.elementor-widget-divider --separator-type-pattern.elementor-widget-divider--view-line .elementor-di vider-separator\,.elementor-widget-divider--separator-type-pattern:not(.el ementor-widget-divider--view-line) .elementor-divider-separator:after\,.el ementor-widget-divider--separator-type-pattern:not(.elementor-widget-divid er--view-line) .elementor-divider-separator:before\,.elementor-widget-divi der--separator-type-pattern:not([class*=elementor-widget-divider--view]) . elementor-divider-separator{width:100%\;min-height:var(--divider-pattern-h eight)\;-webkit-mask-size:var(--divider-pattern-size) 100%\;mask-size:var( --divider-pattern-size) 100%\;-webkit-mask-repeat:var(--divider-pattern-re peat)\;mask-repeat:var(--divider-pattern-repeat)\;background-color:var(--d ivider-color)\;-webkit-mask-image:var(--divider-pattern-url)\;mask-image:v ar(--divider-pattern-url)}.elementor-widget-divider--no-spacing{--divider- pattern-size:auto}.elementor-widget-divider--bg-round{--divider-pattern-re peat:round}.rtl .elementor-widget-divider .elementor-divider__text{directi on:rtl}.e-con-inner>.elementor-widget-divider\,.e-con>.elementor-widget-di vider{width:var(--container-widget-width)\;--flex-grow:var(--container-wid get-flex-grow)}SESSION 1 - JBCC May 2018 6th Edition: Clause 23.0 Guidelin es on How to Administer Extension of Time for Practical CompletionPresente r: Professor MaritzContinued Professional DevelopmentThe Importance of Con tract LawApplication of law in RSA – Time barringThe JBCC Standard Contr act and Contract DataDefinitions and interpretationExecutionExecution Comp letionExtension of timeRevision of date of PCPenaltiesObjectives:• Delay s where the contractor is not at fault would normally constitute a valid c laim for (EOT).• Delays affects critical path of projects.• Confirming a delay and/ or disruption is not an easy task: it is a time-consuming pr ocess\, especially in multifaceted projects with thousands of activities\, a lot of details\,  as well as the involvement of many stakeholders.• It is important for clients\, contractors\, sub-contractors\, and consulta nts to understand the fundamental requirements of compiling a successful E OT claim\, and the adjudication of claims submitted.• These training not es will provide those involved in the preparation and adjudication of EOT claims under the JBCC with some essential information to deal more product ively with this complex matter.• On larger projects\, the magnitude of t ime-related costs can easily run into millions of rand. With so much at st ake\, it is understandable that delay claims are a major source of dispute s in the construction industry.• The proper assessment of delay claims i s essential so that the parties can deal with it without having to resolve the dispute in expensive and drawn-out arbitration or litigation processe s.Learning Outcomes:Identify delays where the contractor is not at fault\, which would constitute a valid claim for (EOT).Users will be able to avoi d delays which affectDelegates will be equipped with dealing with delays a nd/ or disruption in multifaceted projects with thousands of activities\, a lot of details\, as well as the involvement of many stakeholders.The imp ortance for clients\, contractors\, sub-contractors\, and consultants to u nderstand the fundamental requirements of compiling a successful EOT claim \, and the adjudication of claims submitted.This training will provide tho se involved in the preparation and adjudication of EOT claims under the JB CC with some essential information to deal more productively with this com plex matter.On larger projects\, the magnitude of time-related costs can e asily run into millions of With so much at stake\, it is understandable th at delay claims are a major source of disputes in the construction industr y.Delegates will be enabled to properly do assessment of delay claims so t hat the parties can deal with it without having to resolve the dispute in expensive and drawn-out arbitration or litigationSESSION 2JBCC MAY 2018 6t h Edition: Understanding The Roles of The Various Role Players Involved in The Building Contract with Emphasis on The Role of The Principal AgentPre senter: Gerard DamstraDefinition of Principal AgentWho to choose as a Prin cipal AgentDuties of a Principal AgentDelegated powers of a Principal Agen tDuties of a Principal Agent derived from the PBA edition 6.2. Learning Ou tcomes:Implement approval of the contractor consenting to a nominated subc ontractor to assign or cede to his rights and obligations.Hold the contrac t documents (if so\, agreed in the contract data).Supply the contractor wi th drawings\, un-priced bills of quantities and other documents as listed in the schedule at the expense of the employer.Notify contractor of delega tions of authority of agentsDeal with notices received from contractor whe re any agent fails to act in terms of delegated authority.Timeously accept the design undertaken by a selected subcontractorInform employer of date upon which responsibility for works passes to employer.Measure and add val ue of physical loss or damage to the works where contractor is not liable. Deal with notices from contractor of loss and damage to the works.Dealing with notices from contractors is an unavoidable result of the execution of the works not depicted in construction information.Ditto\, for alteration s and additionsBe able to inform employer of date upon which responsibilit y for works passes to employer.Delegate authority to agent responsible for design of lateral support.Who can attend:Principal Agents and Project Man agersArchitectsQuantity SurveyorsEngineersBuilding Contractors and Subcont ractorsEmployersBuilding Owners\, DevelopersProcurement OfficersProject Fi nanciersLegal AdvisorsVIRTUAL SEMINAR COST : Single delegate  |  R1 7 50.00Multiple delegates (2 or more)  |  R1 500.00JBCC webinar from 13h 00 -16h00Time shows in JohannesburgEARN CPD CREDITS!  TOTAL OF  4 HOUR S(Each session: 3 hours and 1 hour for quiz completion)*PLEASE NOTE: Regi ster with the email address that you will use to access the webinar on the day of the sessions.*/*! elementor - v3.10.2 - 29-01-2023 */.elementor-co lumn .elementor-spacer-inner{height:var(--spacer-size)}.e-con{--container- widget-width:100%}.e-con-inner>.elementor-widget-spacer\,.e-con>.elementor -widget-spacer{width:var(--container-widget-width\,var(--spacer-size))\;-- align-self:var(--container-widget-align-self\,initial)\;--flex-shrink:0}.e -con-inner>.elementor-widget-spacer>.elementor-widget-container\,.e-con-in ner>.elementor-widget-spacer>.elementor-widget-container>.elementor-spacer \,.e-con>.elementor-widget-spacer>.elementor-widget-container\,.e-con>.ele mentor-widget-spacer>.elementor-widget-container>.elementor-spacer{height: 100%}.e-con-inner>.elementor-widget-spacer>.elementor-widget-container>.el ementor-spacer>.elementor-spacer-inner\,.e-con>.elementor-widget-spacer>.e lementor-widget-container>.elementor-spacer>.elementor-spacer-inner{height :var(--container-widget-height\,var(--spacer-size))}REGISTER HERE ATTACH;FMTTYPE=image/jpeg:https://jbcc.co.za/wp-content/uploads/2019/01/se rvices-3-960x600-1.jpeg END:VEVENT BEGIN:VEVENT UID:11@jbcc.co.za DTSTART;TZID=Africa/Johannesburg:20230711T130000 DTEND;TZID=Africa/Johannesburg:20230711T160000 DTSTAMP:20230421T102149Z URL:https://jbcc.co.za/events/extension-of-time-and-role-of-the-principal- agent-webinar-11-july-2023/ SUMMARY:EXTENSION OF TIME AND ROLE OF THE PRINCIPAL AGENT WEBINAR - 11 July 2023 DESCRIPTION:JBCC MAY 2018 6TH EDITION: CLAUSE 23.0GUIDELINES ON HOW TO ADMI NISTER EXTENSION OF TIME FOR PRACTICAL COMPLETIONPresented by – Professo r Maritz &\; Gerard Damstra/*! elementor - v3.10.2 - 29-01-2023 */.elem entor-widget-divider{--divider-border-style:none\;--divider-border-width:1 px\;--divider-color:#2c2c2c\;--divider-icon-size:20px\;--divider-element-s pacing:10px\;--divider-pattern-height:24px\;--divider-pattern-size:20px\;- -divider-pattern-url:none\;--divider-pattern-repeat:repeat-x}.elementor-wi dget-divider .elementor-divider{display:flex}.elementor-widget-divider .el ementor-divider__text{font-size:15px\;line-height:1\;max-width:95%}.elemen tor-widget-divider .elementor-divider__element{margin:0 var(--divider-elem ent-spacing)\;flex-shrink:0}.elementor-widget-divider .elementor-icon{font -size:var(--divider-icon-size)}.elementor-widget-divider .elementor-divide r-separator{display:flex\;margin:0\;direction:ltr}.elementor-widget-divide r--view-line_icon .elementor-divider-separator\,.elementor-widget-divider- -view-line_text .elementor-divider-separator{align-items:center}.elementor -widget-divider--view-line_icon .elementor-divider-separator:after\,.eleme ntor-widget-divider--view-line_icon .elementor-divider-separator:before\,. elementor-widget-divider--view-line_text .elementor-divider-separator:afte r\,.elementor-widget-divider--view-line_text .elementor-divider-separator: before{display:block\;content:""\;border-bottom:0\;flex-grow:1\;border-top :var(--divider-border-width) var(--divider-border-style) var(--divider-col or)}.elementor-widget-divider--element-align-left .elementor-divider .elem entor-divider-separator>.elementor-divider__svg:first-of-type{flex-grow:0\ ;flex-shrink:100}.elementor-widget-divider--element-align-left .elementor- divider-separator:before{content:none}.elementor-widget-divider--element-a lign-left .elementor-divider__element{margin-left:0}.elementor-widget-divi der--element-align-right .elementor-divider .elementor-divider-separator>. elementor-divider__svg:last-of-type{flex-grow:0\;flex-shrink:100}.elemento r-widget-divider--element-align-right .elementor-divider-separator:after{c ontent:none}.elementor-widget-divider--element-align-right .elementor-divi der__element{margin-right:0}.elementor-widget-divider:not(.elementor-widge t-divider--view-line_text):not(.elementor-widget-divider--view-line_icon) .elementor-divider-separator{border-top:var(--divider-border-width) var(-- divider-border-style) var(--divider-color)}.elementor-widget-divider--sepa rator-type-pattern{--divider-border-style:none}.elementor-widget-divider-- separator-type-pattern.elementor-widget-divider--view-line .elementor-divi der-separator\,.elementor-widget-divider--separator-type-pattern:not(.elem entor-widget-divider--view-line) .elementor-divider-separator:after\,.elem entor-widget-divider--separator-type-pattern:not(.elementor-widget-divider --view-line) .elementor-divider-separator:before\,.elementor-widget-divide r--separator-type-pattern:not([class*=elementor-widget-divider--view]) .el ementor-divider-separator{width:100%\;min-height:var(--divider-pattern-hei ght)\;-webkit-mask-size:var(--divider-pattern-size) 100%\;mask-size:var(-- divider-pattern-size) 100%\;-webkit-mask-repeat:var(--divider-pattern-repe at)\;mask-repeat:var(--divider-pattern-repeat)\;background-color:var(--div ider-color)\;-webkit-mask-image:var(--divider-pattern-url)\;mask-image:var (--divider-pattern-url)}.elementor-widget-divider--no-spacing{--divider-pa ttern-size:auto}.elementor-widget-divider--bg-round{--divider-pattern-repe at:round}.rtl .elementor-widget-divider .elementor-divider__text{direction :rtl}.e-con-inner>.elementor-widget-divider\,.e-con>.elementor-widget-divi der{width:var(--container-widget-width)\;--flex-grow:var(--container-widge t-flex-grow)}SESSION 1JBCC May 2018 6th Edition: Clause 23.0 Guidelines on How to Administer Extension of Time for Practical CompletionPresenter: Pr ofessor Maritz• Delays where the contractor is not at fault would normal ly constitute a valid claim for (EOT).• Delays affects critical path of projects.• Confirming a delay and/ or disruption is not an easy task: it is a time-consuming process\, especially in multifaceted projects with th ousands of activities\, a lot of details\, as well as the involvement of m any stakeholders.• It is important for clients\, contractors\, sub-contr actors\, and consultants to understand the fundamental requirements of com piling a successful EOT claim\, and the adjudication of claims submitted. • These training notes will provide those involved in the preparation an d adjudication of EOT claims under the JBCC with some essential informatio n to deal more productively with this complex matter.• On larger project s\, the magnitude of time-related costs can easily run into millions of ra nd. With so much at stake\, it is understandable that delay claims are a m ajor source of disputes in the construction industry.• The proper assess ment of delay claims is essential so that the parties can deal with it wit hout having to resolve the dispute in expensive and drawn-out arbitration or litigation processes.SESSION 2JBCC MAY 2018 6th Edition: Understanding The Roles of The Various Role Players Involved in The Building Contract wi th Emphasis on The Role of The Principal AgentPresenter: Gerard Damstra• The building contract involves a host of role players to establish a succ essful project - role players all have specific functions to be performed within specific boundaries\, with specific powers entrusted to them.• Ro le players must work together to ensure a successful project is completed within timeframes and with professionalism\, integrity\, honesty and moral standards.• Some functions are regulated by contracts between role play ers\, but others are governed by the standards laid down by society – th e so-called boni mores of a community.• Role players must be aware of th e impact of their actions.• It is imperative that all parties involved i n a project have proper detailed knowledge of their respective roles\, pow ers\, duties\, timelines and application of specialised professional contr ibutions to the “team.”• It is the function of the principal agent t o bring all the aspects\, required for a successful building project\, tog ether in a coordinated and orderly manner.• The role of the principal ag ent therefore requires a proper understanding or else a project may fall a part to the detriment of all parties involved.• If the role of the princ ipal agent is not fully understood\, chaos may be the result in which all parties suffer financial loss\, impaired reputations and environmental dam age.VIRTUAL SEMINAR COST : Single delegate  |  R1 750.00Multiple dele gates (2 or more)  |  R1 500.00One day webinar from 13h00 -16h00Time s hows in JohannesburgEARN CPD CREDITS!  TOTAL OF 7 HOURS(Each session: 3 hours and 1 hour for quiz completion)*PLEASE NOTE: Register with the ema il address that you will use to access the webinar on the day of the sessi ons.*/*! elementor - v3.10.2 - 29-01-2023 */.elementor-column .elementor-s pacer-inner{height:var(--spacer-size)}.e-con{--container-widget-width:100% }.e-con-inner>.elementor-widget-spacer\,.e-con>.elementor-widget-spacer{wi dth:var(--container-widget-width\,var(--spacer-size))\;--align-self:var(-- container-widget-align-self\,initial)\;--flex-shrink:0}.e-con-inner>.eleme ntor-widget-spacer>.elementor-widget-container\,.e-con-inner>.elementor-wi dget-spacer>.elementor-widget-container>.elementor-spacer\,.e-con>.element or-widget-spacer>.elementor-widget-container\,.e-con>.elementor-widget-spa cer>.elementor-widget-container>.elementor-spacer{height:100%}.e-con-inner >.elementor-widget-spacer>.elementor-widget-container>.elementor-spacer>.e lementor-spacer-inner\,.e-con>.elementor-widget-spacer>.elementor-widget-c ontainer>.elementor-spacer>.elementor-spacer-inner{height:var(--container- widget-height\,var(--spacer-size))}REGISTER HERE ATTACH;FMTTYPE=image/jpeg:https://jbcc.co.za/wp-content/uploads/2019/01/se rvices-3-960x600-1.jpeg END:VEVENT BEGIN:VEVENT UID:17@jbcc.co.za DTSTART;TZID=Africa/Johannesburg:20230718T130000 DTEND;TZID=Africa/Johannesburg:20230719T160000 DTSTAMP:20230714T072125Z URL:https://jbcc.co.za/events/jbcc-agreements-contracts-2018-2020-july-202 3-2/ SUMMARY:JBCC AGREEMENTS/CONTRACTS 2018/2020 - July 2023 DESCRIPTION:This is a training course conducted online using zoom presented in two sessions starting from 13h00 and ends at 16h00Presented by  – P rofessor MaritzObjectives:The interpretation and understanding of the JBCC agreements and contracts is fundamental in carrying out a successful cons truction project to final completion stage. Many projects stand still due the lack of contract knowledge in implementation. It is crucial that contr acting parties adhere and fully understand the JBCC clauses before enterin g a JBCC agreement. This webinar reviews the JBCC clauses from implementat ion of a project to the final completion stages and gives a view to the de legates the challenges that might be experienced in progamme stages\, reme dies that can be used and what to avoid when administering a project using the JBCC agreements.Learning Outcomes:Describe the development of the var ious types of building contracts in use in South Africa\;Identify the impo rtant role of the JBCC documents in the South African building industry\;H ave an in-depth understanding of the historical background and structure o f the JBCC May 2018 6.2nd Ed\;Know what the JBCC documents comprise of and its application in the South African building industry and elsewhere in A frica\;Know what the duties are of the Principal Agent arising from the JB CC documents\; andUnderstand the mechanisms and day-to-day use of a select ion of commonly encountered provisions.SESSION 1Construction LawPre-Contra ct ActivitiesRisk Management Procurement / Contract DataDispute Resolution MediationAdjudicationArbitrationDefinitionsOffer and Acceptance DocumentsA gents/ Design Duties of the PartiesSubcontractorsSESSION 2Contract Instruc tionsExecution &\; Completion Penalties (Damages)PaymentsAdjustment of the Contract ValueInsurances &\; SecuritiesSuspension &\; Terminatio nDifferences between editions 4.1\, 6. 1 and 6.2State Contract DataNew Con tracts (SSWC &\; DCC)Who Can Attend:Principal Agents and Project Manage rsArchitectsQuantity SurveyorsEngineersBuilding Contractors and Subcontrac torsEmployersBuilding Owners\, DevelopersProcurement OfficersProject Finan ciersLegal AdvisorsVIRTUAL SEMINAR COST (FOR BOTH SESSIONS): Single deleg ate  |  R3 575.00Multiple delegates (2 or more)  |  R3 300.00Sessi on 1:July 18\, 2023 01:00 PM Session 2:July 19\, 2023 01:00 PMTime shows i n JohannesburgEARN CPD CREDITS!  TOTAL OF 7 HOURS(Each session: 3 hours and 1 hour for quiz completion)*PLEASE NOTE: Register with the email add ress that you will use to access the webinar on the day of the sessions.*/ *! elementor - v3.10.2 - 29-01-2023 */.elementor-column .elementor-spacer- inner{height:var(--spacer-size)}.e-con{--container-widget-width:100%}.e-co n-inner>.elementor-widget-spacer\,.e-con>.elementor-widget-spacer{width:va r(--container-widget-width\,var(--spacer-size))\;--align-self:var(--contai ner-widget-align-self\,initial)\;--flex-shrink:0}.e-con-inner>.elementor-w idget-spacer>.elementor-widget-container\,.e-con-inner>.elementor-widget-s pacer>.elementor-widget-container>.elementor-spacer\,.e-con>.elementor-wid get-spacer>.elementor-widget-container\,.e-con>.elementor-widget-spacer>.e lementor-widget-container>.elementor-spacer{height:100%}.e-con-inner>.elem entor-widget-spacer>.elementor-widget-container>.elementor-spacer>.element or-spacer-inner\,.e-con>.elementor-widget-spacer>.elementor-widget-contain er>.elementor-spacer>.elementor-spacer-inner{height:var(--container-widget -height\,var(--spacer-size))}REGISTER HERE ATTACH;FMTTYPE=image/jpeg:https://jbcc.co.za/wp-content/uploads/2019/01/se rvices-3-960x600-1.jpeg END:VEVENT BEGIN:VEVENT UID:12@jbcc.co.za DTSTART;TZID=Africa/Johannesburg:20230814T130000 DTEND;TZID=Africa/Johannesburg:20230814T160000 DTSTAMP:20230614T075411Z URL:https://jbcc.co.za/events/extension-of-time-and-role-of-the-principal- agent-webinar-15-aug-2023/ SUMMARY:EXTENSION OF TIME AND ROLE OF THE PRINCIPAL AGENT WEBINAR - 15 Augu st 2023 DESCRIPTION:JBCC MAY 2018 6TH EDITION: CLAUSE 23.0\nGUIDELINES ON HOW TO AD MINISTER EXTENSION OF TIME FOR PRACTICAL COMPLETION\nPresented by – Prof essor Maritz &\; Gerard Damstra\n\n/*! elementor - v3.10.2 - 29-01-2023 */.elementor-widget-divider{--divider-border-style:none\;--divider-border -width:1px\;--divider-color:#2c2c2c\;--divider-icon-size:20px\;--divider-e lement-spacing:10px\;--divider-pattern-height:24px\;--divider-pattern-size :20px\;--divider-pattern-url:none\;--divider-pattern-repeat:repeat-x}.elem entor-widget-divider .elementor-divider{display:flex}.elementor-widget-div ider .elementor-divider__text{font-size:15px\;line-height:1\;max-width:95% }.elementor-widget-divider .elementor-divider__element{margin:0 var(--divi der-element-spacing)\;flex-shrink:0}.elementor-widget-divider .elementor-i con{font-size:var(--divider-icon-size)}.elementor-widget-divider .elemento r-divider-separator{display:flex\;margin:0\;direction:ltr}.elementor-widge t-divider--view-line_icon .elementor-divider-separator\,.elementor-widget- divider--view-line_text .elementor-divider-separator{align-items:center}.e lementor-widget-divider--view-line_icon .elementor-divider-separator:after \,.elementor-widget-divider--view-line_icon .elementor-divider-separator:b efore\,.elementor-widget-divider--view-line_text .elementor-divider-separa tor:after\,.elementor-widget-divider--view-line_text .elementor-divider-se parator:before{display:block\;content:""\;border-bottom:0\;flex-grow:1\;bo rder-top:var(--divider-border-width) var(--divider-border-style) var(--div ider-color)}.elementor-widget-divider--element-align-left .elementor-divid er .elementor-divider-separator>.elementor-divider__svg:first-of-type{flex -grow:0\;flex-shrink:100}.elementor-widget-divider--element-align-left .el ementor-divider-separator:before{content:none}.elementor-widget-divider--e lement-align-left .elementor-divider__element{margin-left:0}.elementor-wid get-divider--element-align-right .elementor-divider .elementor-divider-sep arator>.elementor-divider__svg:last-of-type{flex-grow:0\;flex-shrink:100}. elementor-widget-divider--element-align-right .elementor-divider-separator :after{content:none}.elementor-widget-divider--element-align-right .elemen tor-divider__element{margin-right:0}.elementor-widget-divider:not(.element or-widget-divider--view-line_text):not(.elementor-widget-divider--view-lin e_icon) .elementor-divider-separator{border-top:var(--divider-border-width ) var(--divider-border-style) var(--divider-color)}.elementor-widget-divid er--separator-type-pattern{--divider-border-style:none}.elementor-widget-d ivider--separator-type-pattern.elementor-widget-divider--view-line .elemen tor-divider-separator\,.elementor-widget-divider--separator-type-pattern:n ot(.elementor-widget-divider--view-line) .elementor-divider-separator:afte r\,.elementor-widget-divider--separator-type-pattern:not(.elementor-widget -divider--view-line) .elementor-divider-separator:before\,.elementor-widge t-divider--separator-type-pattern:not([class*=elementor-widget-divider--vi ew]) .elementor-divider-separator{width:100%\;min-height:var(--divider-pat tern-height)\;-webkit-mask-size:var(--divider-pattern-size) 100%\;mask-siz e:var(--divider-pattern-size) 100%\;-webkit-mask-repeat:var(--divider-patt ern-repeat)\;mask-repeat:var(--divider-pattern-repeat)\;background-color:v ar(--divider-color)\;-webkit-mask-image:var(--divider-pattern-url)\;mask-i mage:var(--divider-pattern-url)}.elementor-widget-divider--no-spacing{--di vider-pattern-size:auto}.elementor-widget-divider--bg-round{--divider-patt ern-repeat:round}.rtl .elementor-widget-divider .elementor-divider__text{d irection:rtl}.e-con-inner>.elementor-widget-divider\,.e-con>.elementor-wid get-divider{width:var(--container-widget-width)\;--flex-grow:var(--contain er-widget-flex-grow)}\n\nSESSION 1\nJBCC May 2018 6th Edition: Clause 23.0 Guidelines on How to Administer Extension of Time for Practical Completio n\n\nPresenter: Professor Maritz\n\n• Delays where the contractor is not at fault would normally constitute a valid claim for (EOT).\n• Delays a ffects critical path of projects.\n• Confirming a delay and/ or disrupti on is not an easy task: it is a time-consuming process\, especially in mul tifaceted projects with thousands of activities\, a lot of details\, as we ll as the involvement of many stakeholders.\n• It is important for clien ts\, contractors\, sub-contractors\, and consultants to understand the fun damental requirements of compiling a successful EOT claim\, and the adjudi cation of claims submitted.\n• These training notes will provide those i nvolved in the preparation and adjudication of EOT claims under the JBCC w ith some essential information to deal more productively with this complex matter.\n• On larger projects\, the magnitude of time-related costs can easily run into millions of rand. With so much at stake\, it is understan dable that delay claims are a major source of disputes in the construction industry.\n• The proper assessment of delay claims is essential so that the parties can deal with it without having to resolve the dispute in exp ensive and drawn-out arbitration or litigation processes.\n\nSESSION 2\n\n JBCC MAY 2018 6th Edition: Understanding The Roles of The Various Role Pla yers Involved in The Building Contract with Emphasis on The Role of The Pr incipal Agent\n\nPresenter: Gerard Damstra\n\n• The building contract in volves a host of role players to establish a successful project - role pla yers all have specific functions to be performed within specific boundarie s\, with specific powers entrusted to them.\n• Role players must work to gether to ensure a successful project is completed within timeframes and w ith professionalism\, integrity\, honesty and moral standards.\n• Some f unctions are regulated by contracts between role players\, but others are governed by the standards laid down by society – the so-called boni more s of a community.\n• Role players must be aware of the impact of their a ctions.\n• It is imperative that all parties involved in a project have proper detailed knowledge of their respective roles\, powers\, duties\, ti melines and application of specialised professional contributions to the “team.”\n• It is the function of the principal agent to bring all th e aspects\, required for a successful building project\, together in a coo rdinated and orderly manner.\n• The role of the principal agent therefor e requires a proper understanding or else a project may fall apart to the detriment of all parties involved.\n• If the role of the principal agent is not fully understood\, chaos may be the result in which all parties su ffer financial loss\, impaired reputations and environmental damage.\nVIRT UAL SEMINAR COST : \nSingle delegate  |  R1 750.00\nMultiple delegate s (2 or more)  |  R1 500.00\n\nOne day webinar from 13h00 -16h00\n\nTi me shows in Johannesburg\n\nEARN CPD CREDITS!  TOTAL OF 7 HOURS\n(Each session: 3 hours and 1 hour for quiz completion)\n*PLEASE NOTE: Register with the email address that you will use to access the webinar on the day of the sessions.*\n/*! elementor - v3.10.2 - 29-01-2023 */.elementor-colum n .elementor-spacer-inner{height:var(--spacer-size)}.e-con{--container-wid get-width:100%}.e-con-inner>.elementor-widget-spacer\,.e-con>.elementor-wi dget-spacer{width:var(--container-widget-width\,var(--spacer-size))\;--ali gn-self:var(--container-widget-align-self\,initial)\;--flex-shrink:0}.e-co n-inner>.elementor-widget-spacer>.elementor-widget-container\,.e-con-inner >.elementor-widget-spacer>.elementor-widget-container>.elementor-spacer\,. e-con>.elementor-widget-spacer>.elementor-widget-container\,.e-con>.elemen tor-widget-spacer>.elementor-widget-container>.elementor-spacer{height:100 %}.e-con-inner>.elementor-widget-spacer>.elementor-widget-container>.eleme ntor-spacer>.elementor-spacer-inner\,.e-con>.elementor-widget-spacer>.elem entor-widget-container>.elementor-spacer>.elementor-spacer-inner{height:va r(--container-widget-height\,var(--spacer-size))}\n\n\nREGISTER HERE\n ATTACH;FMTTYPE=image/jpeg:https://jbcc.co.za/wp-content/uploads/2019/01/se rvices-3-960x600-1.jpeg END:VEVENT BEGIN:VEVENT UID:18@jbcc.co.za DTSTART;TZID=Africa/Johannesburg:20230815T130000 DTEND;TZID=Africa/Johannesburg:20230816T160000 DTSTAMP:20230728T074828Z URL:https://jbcc.co.za/events/jbcc-agreements-contracts-2018-2020-august-2 023/ SUMMARY:JBCC AGREEMENTS/CONTRACTS 2018/2020 - August 2023 DESCRIPTION:This is a training course conducted online using zoom presented in two sessions starting from 13h00 and ends at 16h00Presented by  – P rofessor MaritzObjectives:The interpretation and understanding of the JBCC agreements and contracts is fundamental in carrying out a successful cons truction project to final completion stage. Many projects stand still due the lack of contract knowledge in implementation. It is crucial that contr acting parties adhere and fully understand the JBCC clauses before enterin g a JBCC agreement. This webinar reviews the JBCC clauses from implementat ion of a project to the final completion stages and gives a view to the de legates the challenges that might be experienced in progamme stages\, reme dies that can be used and what to avoid when administering a project using the JBCC agreements.Learning Outcomes:Describe the development of the var ious types of building contracts in use in South Africa\;Identify the impo rtant role of the JBCC documents in the South African building industry\;H ave an in-depth understanding of the historical background and structure o f the JBCC May 2018 6.2nd Ed\;Know what the JBCC documents comprise of and its application in the South African building industry and elsewhere in A frica\;Know what the duties are of the Principal Agent arising from the JB CC documents\; andUnderstand the mechanisms and day-to-day use of a select ion of commonly encountered provisions.SESSION 1Construction LawPre-Contra ct ActivitiesRisk Management Procurement / Contract DataDispute Resolution MediationAdjudicationArbitrationDefinitionsOffer and Acceptance DocumentsA gents/ Design Duties of the PartiesSubcontractorsSESSION 2Contract Instruc tionsExecution &\; Completion Penalties (Damages)PaymentsAdjustment of the Contract ValueInsurances &\; SecuritiesSuspension &\; Terminatio nDifferences between editions 4.1\, 6. 1 and 6.2State Contract DataNew Con tracts (SSWC &\; DCC)Who Can Attend:Principal Agents and Project Manage rsArchitectsQuantity SurveyorsEngineersBuilding Contractors and Subcontrac torsEmployersBuilding Owners\, DevelopersProcurement OfficersProject Finan ciersLegal AdvisorsVIRTUAL SEMINAR COST (FOR BOTH SESSIONS): Single deleg ate  |  R3 575.00Multiple delegates (2 or more)  |  R3 300.00Sessi on 1:August 15\, 2023 01:00 PM Session 2:August 16\, 2023 01:00 PMTime sho ws in JohannesburgEARN CPD CREDITS!  TOTAL OF 7 HOURS(Each session: 3 h ours and 1 hour for quiz completion)*PLEASE NOTE: Register with the email address that you will use to access the webinar on the day of the session s.*/*! elementor - v3.10.2 - 29-01-2023 */.elementor-column .elementor-spa cer-inner{height:var(--spacer-size)}.e-con{--container-widget-width:100%}. e-con-inner>.elementor-widget-spacer\,.e-con>.elementor-widget-spacer{widt h:var(--container-widget-width\,var(--spacer-size))\;--align-self:var(--co ntainer-widget-align-self\,initial)\;--flex-shrink:0}.e-con-inner>.element or-widget-spacer>.elementor-widget-container\,.e-con-inner>.elementor-widg et-spacer>.elementor-widget-container>.elementor-spacer\,.e-con>.elementor -widget-spacer>.elementor-widget-container\,.e-con>.elementor-widget-space r>.elementor-widget-container>.elementor-spacer{height:100%}.e-con-inner>. elementor-widget-spacer>.elementor-widget-container>.elementor-spacer>.ele mentor-spacer-inner\,.e-con>.elementor-widget-spacer>.elementor-widget-con tainer>.elementor-spacer>.elementor-spacer-inner{height:var(--container-wi dget-height\,var(--spacer-size))}REGISTER HERE ATTACH;FMTTYPE=image/jpeg:https://jbcc.co.za/wp-content/uploads/2019/01/se rvices-3-960x600-1.jpeg END:VEVENT BEGIN:VEVENT UID:13@jbcc.co.za DTSTART;TZID=Africa/Johannesburg:20230919T130000 DTEND;TZID=Africa/Johannesburg:20230919T160000 DTSTAMP:20230822T072551Z URL:https://jbcc.co.za/events/extension-of-time-and-role-of-the-principal- agent-webinar-19-sep-2023/ SUMMARY:EXTENSION OF TIME AND ROLE OF THE PRINCIPAL AGENT WEBINAR - 19 Sept ember 2023 DESCRIPTION:JBCC MAY 2018 6TH EDITION: CLAUSE 23.0GUIDELINES ON HOW TO ADMI NISTER EXTENSION OF TIME FOR PRACTICAL COMPLETIONPresented by – Professo r Maritz &\; Gerard Damstra/*! elementor - v3.10.2 - 29-01-2023 */.elem entor-widget-divider{--divider-border-style:none\;--divider-border-width:1 px\;--divider-color:#2c2c2c\;--divider-icon-size:20px\;--divider-element-s pacing:10px\;--divider-pattern-height:24px\;--divider-pattern-size:20px\;- -divider-pattern-url:none\;--divider-pattern-repeat:repeat-x}.elementor-wi dget-divider .elementor-divider{display:flex}.elementor-widget-divider .el ementor-divider__text{font-size:15px\;line-height:1\;max-width:95%}.elemen tor-widget-divider .elementor-divider__element{margin:0 var(--divider-elem ent-spacing)\;flex-shrink:0}.elementor-widget-divider .elementor-icon{font -size:var(--divider-icon-size)}.elementor-widget-divider .elementor-divide r-separator{display:flex\;margin:0\;direction:ltr}.elementor-widget-divide r--view-line_icon .elementor-divider-separator\,.elementor-widget-divider- -view-line_text .elementor-divider-separator{align-items:center}.elementor -widget-divider--view-line_icon .elementor-divider-separator:after\,.eleme ntor-widget-divider--view-line_icon .elementor-divider-separator:before\,. elementor-widget-divider--view-line_text .elementor-divider-separator:afte r\,.elementor-widget-divider--view-line_text .elementor-divider-separator: before{display:block\;content:""\;border-bottom:0\;flex-grow:1\;border-top :var(--divider-border-width) var(--divider-border-style) var(--divider-col or)}.elementor-widget-divider--element-align-left .elementor-divider .elem entor-divider-separator>.elementor-divider__svg:first-of-type{flex-grow:0\ ;flex-shrink:100}.elementor-widget-divider--element-align-left .elementor- divider-separator:before{content:none}.elementor-widget-divider--element-a lign-left .elementor-divider__element{margin-left:0}.elementor-widget-divi der--element-align-right .elementor-divider .elementor-divider-separator>. elementor-divider__svg:last-of-type{flex-grow:0\;flex-shrink:100}.elemento r-widget-divider--element-align-right .elementor-divider-separator:after{c ontent:none}.elementor-widget-divider--element-align-right .elementor-divi der__element{margin-right:0}.elementor-widget-divider:not(.elementor-widge t-divider--view-line_text):not(.elementor-widget-divider--view-line_icon) .elementor-divider-separator{border-top:var(--divider-border-width) var(-- divider-border-style) var(--divider-color)}.elementor-widget-divider--sepa rator-type-pattern{--divider-border-style:none}.elementor-widget-divider-- separator-type-pattern.elementor-widget-divider--view-line .elementor-divi der-separator\,.elementor-widget-divider--separator-type-pattern:not(.elem entor-widget-divider--view-line) .elementor-divider-separator:after\,.elem entor-widget-divider--separator-type-pattern:not(.elementor-widget-divider --view-line) .elementor-divider-separator:before\,.elementor-widget-divide r--separator-type-pattern:not([class*=elementor-widget-divider--view]) .el ementor-divider-separator{width:100%\;min-height:var(--divider-pattern-hei ght)\;-webkit-mask-size:var(--divider-pattern-size) 100%\;mask-size:var(-- divider-pattern-size) 100%\;-webkit-mask-repeat:var(--divider-pattern-repe at)\;mask-repeat:var(--divider-pattern-repeat)\;background-color:var(--div ider-color)\;-webkit-mask-image:var(--divider-pattern-url)\;mask-image:var (--divider-pattern-url)}.elementor-widget-divider--no-spacing{--divider-pa ttern-size:auto}.elementor-widget-divider--bg-round{--divider-pattern-repe at:round}.rtl .elementor-widget-divider .elementor-divider__text{direction :rtl}.e-con-inner>.elementor-widget-divider\,.e-con>.elementor-widget-divi der{width:var(--container-widget-width)\;--flex-grow:var(--container-widge t-flex-grow)}SESSION 1JBCC May 2018 6th Edition: Clause 23.0 Guidelines on How to Administer Extension of Time for Practical CompletionPresenter: Pr ofessor Maritz• Delays where the contractor is not at fault would normal ly constitute a valid claim for (EOT).• Delays affects critical path of projects.• Confirming a delay and/ or disruption is not an easy task: it is a time-consuming process\, especially in multifaceted projects with th ousands of activities\, a lot of details\, as well as the involvement of m any stakeholders.• It is important for clients\, contractors\, sub-contr actors\, and consultants to understand the fundamental requirements of com piling a successful EOT claim\, and the adjudication of claims submitted. • These training notes will provide those involved in the preparation an d adjudication of EOT claims under the JBCC with some essential informatio n to deal more productively with this complex matter.• On larger project s\, the magnitude of time-related costs can easily run into millions of ra nd. With so much at stake\, it is understandable that delay claims are a m ajor source of disputes in the construction industry.• The proper assess ment of delay claims is essential so that the parties can deal with it wit hout having to resolve the dispute in expensive and drawn-out arbitration or litigation processes.SESSION 2JBCC MAY 2018 6th Edition: Understanding The Roles of The Various Role Players Involved in The Building Contract wi th Emphasis on The Role of The Principal AgentPresenter: Gerard Damstra• The building contract involves a host of role players to establish a succ essful project - role players all have specific functions to be performed within specific boundaries\, with specific powers entrusted to them.• Ro le players must work together to ensure a successful project is completed within timeframes and with professionalism\, integrity\, honesty and moral standards.• Some functions are regulated by contracts between role play ers\, but others are governed by the standards laid down by society – th e so-called boni mores of a community.• Role players must be aware of th e impact of their actions.• It is imperative that all parties involved i n a project have proper detailed knowledge of their respective roles\, pow ers\, duties\, timelines and application of specialised professional contr ibutions to the “team.”• It is the function of the principal agent t o bring all the aspects\, required for a successful building project\, tog ether in a coordinated and orderly manner.• The role of the principal ag ent therefore requires a proper understanding or else a project may fall a part to the detriment of all parties involved.• If the role of the princ ipal agent is not fully understood\, chaos may be the result in which all parties suffer financial loss\, impaired reputations and environmental dam age.VIRTUAL SEMINAR COST : Single delegate  |  R1 750.00Multiple dele gates (2 or more)  |  R1 500.00One day webinar from 13h00 -16h00Time s hows in JohannesburgEARN CPD CREDITS!  TOTAL OF 7 HOURS(Each session: 3 hours and 1 hour for quiz completion)*PLEASE NOTE: Register with the ema il address that you will use to access the webinar on the day of the sessi ons.*/*! elementor - v3.10.2 - 29-01-2023 */.elementor-column .elementor-s pacer-inner{height:var(--spacer-size)}.e-con{--container-widget-width:100% }.e-con-inner>.elementor-widget-spacer\,.e-con>.elementor-widget-spacer{wi dth:var(--container-widget-width\,var(--spacer-size))\;--align-self:var(-- container-widget-align-self\,initial)\;--flex-shrink:0}.e-con-inner>.eleme ntor-widget-spacer>.elementor-widget-container\,.e-con-inner>.elementor-wi dget-spacer>.elementor-widget-container>.elementor-spacer\,.e-con>.element or-widget-spacer>.elementor-widget-container\,.e-con>.elementor-widget-spa cer>.elementor-widget-container>.elementor-spacer{height:100%}.e-con-inner >.elementor-widget-spacer>.elementor-widget-container>.elementor-spacer>.e lementor-spacer-inner\,.e-con>.elementor-widget-spacer>.elementor-widget-c ontainer>.elementor-spacer>.elementor-spacer-inner{height:var(--container- widget-height\,var(--spacer-size))}REGISTER HERE ATTACH;FMTTYPE=image/jpeg:https://jbcc.co.za/wp-content/uploads/2019/01/se rvices-3-960x600-1.jpeg END:VEVENT BEGIN:VEVENT UID:19@jbcc.co.za DTSTART;TZID=Africa/Johannesburg:20230927T130000 DTEND;TZID=Africa/Johannesburg:20230928T160000 DTSTAMP:20230822T073044Z URL:https://jbcc.co.za/events/jbcc-agreements-contracts-2018-2020-august-2 023-copy/ SUMMARY:JBCC AGREEMENTS/CONTRACTS 2018/2020 - September 2023 DESCRIPTION:This is a training course conducted online using zoom presented in two sessions starting from 13h00 and ends at 16h00\nPresented by  – Professor Maritz\nObjectives:\nThe interpretation and understanding of th e JBCC agreements and contracts is fundamental in carrying out a successfu l construction project to final completion stage. Many projects stand stil l due the lack of contract knowledge in implementation. It is crucial that contracting parties adhere and fully understand the JBCC clauses before e ntering a JBCC agreement. This webinar reviews the JBCC clauses from imple mentation of a project to the final completion stages and gives a view to the delegates the challenges that might be experienced in progamme stages\ , remedies that can be used and what to avoid when administering a project using the JBCC agreements.\n\n\n\nLearning Outcomes:\n\n Describe the de velopment of the various types of building contracts in use in South Afric a\;\n Identify the important role of the JBCC documents in the South Afri can building industry\;\n Have an in-depth understanding of the historica l background and structure of the JBCC May 2018 6.2nd Ed\;\n Know what th e JBCC documents comprise of and its application in the South African buil ding industry and elsewhere in Africa\;\n Know what the duties are of the Principal Agent arising from the JBCC documents\; and\n Understand the m echanisms and day-to-day use of a selection of commonly encountered provis ions.\n\n\n\n\nSESSION 1\n\n Construction Law\n Pre-Contract Activities\ n Risk Management Procurement / Contract Data\n Dispute Resolution\nMedi ation\nAdjudication\nArbitration\n Definitions\n Offer and Acceptance Do cuments\n Agents/ Design Duties of the Parties\n Subcontractors\n\nSESSI ON 2\n\n Contract Instructions\n Execution &\; Completion Penalties ( Damages)\n Payments\n Adjustment of the Contract Value\n Insurances &am p\; Securities\n Suspension &\; Termination\n Differences between edi tions 4.1\, 6. 1 and 6.2\n State Contract Data\n New Contracts (SSWC &am p\; DCC)\n\n\n\n\nWho Can Attend:\n\n Principal Agents and Project Manage rs\n Architects\n Quantity Surveyors\n Engineers\n Building Contractor s and Subcontractors\n Employers\n Building Owners\, Developers\n Procu rement Officers\n Project Financiers\n Legal Advisors\n\n\n\n\nVIRTUAL S EMINAR COST (FOR BOTH SESSIONS): \nSingle delegate  |  R3 575.00\nMul tiple delegates (2 or more)  |  R3 300.00\n\nSession 1:August 15\, 202 3 01:00 PM Session 2:August 16\, 2023 01:00 PM\n\nTime shows in Johannesb urg\n\nEARN CPD CREDITS!  TOTAL OF 7 HOURS\n(Each session: 3 hours and 1 hour for quiz completion)\n*PLEASE NOTE: Register with the email address that you will use to access the webinar on the day of the sessions.*\n/*! elementor - v3.10.2 - 29-01-2023 */\n.elementor-column .elementor-spacer- inner{height:var(--spacer-size)}.e-con{--container-widget-width:100%}.e-co n-inner>\;.elementor-widget-spacer\,.e-con>\;.elementor-widget-spacer{ width:var(--container-widget-width\,var(--spacer-size))\;--align-self:var( --container-widget-align-self\,initial)\;--flex-shrink:0}.e-con-inner>\; .elementor-widget-spacer>\;.elementor-widget-container\,.e-con-inner>\ ;.elementor-widget-spacer>\;.elementor-widget-container>\;.elementor-s pacer\,.e-con>\;.elementor-widget-spacer>\;.elementor-widget-container \,.e-con>\;.elementor-widget-spacer>\;.elementor-widget-container>\; .elementor-spacer{height:100%}.e-con-inner>\;.elementor-widget-spacer> \;.elementor-widget-container>\;.elementor-spacer>\;.elementor-spacer- inner\,.e-con>\;.elementor-widget-spacer>\;.elementor-widget-container >\;.elementor-spacer>\;.elementor-spacer-inner{height:var(--container- widget-height\,var(--spacer-size))}\n\n\nREGISTER HERE\n ATTACH;FMTTYPE=image/jpeg:https://jbcc.co.za/wp-content/uploads/2019/01/se rvices-3-960x600-1.jpeg END:VEVENT BEGIN:VEVENT UID:15@jbcc.co.za DTSTART;TZID=Africa/Johannesburg:20231121T130000 DTEND;TZID=Africa/Johannesburg:20231121T160000 DTSTAMP:20231016T103855Z URL:https://jbcc.co.za/events/extension-of-time-and-role-of-the-principal- agent-webinar-21-nov-2023/ SUMMARY:EXTENSION OF TIME AND ROLE OF THE PRINCIPAL AGENT WEBINAR - 21 Nove mber 2023 DESCRIPTION:JBCC MAY 2018 6TH EDITION: CLAUSE 23.0GUIDELINES ON HOW TO ADMI NISTER EXTENSION OF TIME FOR PRACTICAL COMPLETIONPresented by – Professo r Maritz &\; Gerard Damstra/*! elementor - v3.10.2 - 29-01-2023 */.elem entor-widget-divider{--divider-border-style:none\;--divider-border-width:1 px\;--divider-color:#2c2c2c\;--divider-icon-size:20px\;--divider-element-s pacing:10px\;--divider-pattern-height:24px\;--divider-pattern-size:20px\;- -divider-pattern-url:none\;--divider-pattern-repeat:repeat-x}.elementor-wi dget-divider .elementor-divider{display:flex}.elementor-widget-divider .el ementor-divider__text{font-size:15px\;line-height:1\;max-width:95%}.elemen tor-widget-divider .elementor-divider__element{margin:0 var(--divider-elem ent-spacing)\;flex-shrink:0}.elementor-widget-divider .elementor-icon{font -size:var(--divider-icon-size)}.elementor-widget-divider .elementor-divide r-separator{display:flex\;margin:0\;direction:ltr}.elementor-widget-divide r--view-line_icon .elementor-divider-separator\,.elementor-widget-divider- -view-line_text .elementor-divider-separator{align-items:center}.elementor -widget-divider--view-line_icon .elementor-divider-separator:after\,.eleme ntor-widget-divider--view-line_icon .elementor-divider-separator:before\,. elementor-widget-divider--view-line_text .elementor-divider-separator:afte r\,.elementor-widget-divider--view-line_text .elementor-divider-separator: before{display:block\;content:""\;border-bottom:0\;flex-grow:1\;border-top :var(--divider-border-width) var(--divider-border-style) var(--divider-col or)}.elementor-widget-divider--element-align-left .elementor-divider .elem entor-divider-separator>.elementor-divider__svg:first-of-type{flex-grow:0\ ;flex-shrink:100}.elementor-widget-divider--element-align-left .elementor- divider-separator:before{content:none}.elementor-widget-divider--element-a lign-left .elementor-divider__element{margin-left:0}.elementor-widget-divi der--element-align-right .elementor-divider .elementor-divider-separator>. elementor-divider__svg:last-of-type{flex-grow:0\;flex-shrink:100}.elemento r-widget-divider--element-align-right .elementor-divider-separator:after{c ontent:none}.elementor-widget-divider--element-align-right .elementor-divi der__element{margin-right:0}.elementor-widget-divider:not(.elementor-widge t-divider--view-line_text):not(.elementor-widget-divider--view-line_icon) .elementor-divider-separator{border-top:var(--divider-border-width) var(-- divider-border-style) var(--divider-color)}.elementor-widget-divider--sepa rator-type-pattern{--divider-border-style:none}.elementor-widget-divider-- separator-type-pattern.elementor-widget-divider--view-line .elementor-divi der-separator\,.elementor-widget-divider--separator-type-pattern:not(.elem entor-widget-divider--view-line) .elementor-divider-separator:after\,.elem entor-widget-divider--separator-type-pattern:not(.elementor-widget-divider --view-line) .elementor-divider-separator:before\,.elementor-widget-divide r--separator-type-pattern:not([class*=elementor-widget-divider--view]) .el ementor-divider-separator{width:100%\;min-height:var(--divider-pattern-hei ght)\;-webkit-mask-size:var(--divider-pattern-size) 100%\;mask-size:var(-- divider-pattern-size) 100%\;-webkit-mask-repeat:var(--divider-pattern-repe at)\;mask-repeat:var(--divider-pattern-repeat)\;background-color:var(--div ider-color)\;-webkit-mask-image:var(--divider-pattern-url)\;mask-image:var (--divider-pattern-url)}.elementor-widget-divider--no-spacing{--divider-pa ttern-size:auto}.elementor-widget-divider--bg-round{--divider-pattern-repe at:round}.rtl .elementor-widget-divider .elementor-divider__text{direction :rtl}.e-con-inner>.elementor-widget-divider\,.e-con>.elementor-widget-divi der{width:var(--container-widget-width)\;--flex-grow:var(--container-widge t-flex-grow)}SESSION 1JBCC May 2018 6th Edition: Clause 23.0 Guidelines on How to Administer Extension of Time for Practical CompletionPresenter: Pr ofessor Maritz• Delays where the contractor is not at fault would normal ly constitute a valid claim for (EOT).• Delays affects critical path of projects.• Confirming a delay and/ or disruption is not an easy task: it is a time-consuming process\, especially in multifaceted projects with th ousands of activities\, a lot of details\, as well as the involvement of m any stakeholders.• It is important for clients\, contractors\, sub-contr actors\, and consultants to understand the fundamental requirements of com piling a successful EOT claim\, and the adjudication of claims submitted. • These training notes will provide those involved in the preparation an d adjudication of EOT claims under the JBCC with some essential informatio n to deal more productively with this complex matter.• On larger project s\, the magnitude of time-related costs can easily run into millions of ra nd. With so much at stake\, it is understandable that delay claims are a m ajor source of disputes in the construction industry.• The proper assess ment of delay claims is essential so that the parties can deal with it wit hout having to resolve the dispute in expensive and drawn-out arbitration or litigation processes.SESSION 2JBCC MAY 2018 6th Edition: Understanding The Roles of The Various Role Players Involved in The Building Contract wi th Emphasis on The Role of The Principal AgentPresenter: Gerard Damstra• The building contract involves a host of role players to establish a succ essful project - role players all have specific functions to be performed within specific boundaries\, with specific powers entrusted to them.• Ro le players must work together to ensure a successful project is completed within timeframes and with professionalism\, integrity\, honesty and moral standards.• Some functions are regulated by contracts between role play ers\, but others are governed by the standards laid down by society – th e so-called boni mores of a community.• Role players must be aware of th e impact of their actions.• It is imperative that all parties involved i n a project have proper detailed knowledge of their respective roles\, pow ers\, duties\, timelines and application of specialised professional contr ibutions to the “team.”• It is the function of the principal agent t o bring all the aspects\, required for a successful building project\, tog ether in a coordinated and orderly manner.• The role of the principal ag ent therefore requires a proper understanding or else a project may fall a part to the detriment of all parties involved.• If the role of the princ ipal agent is not fully understood\, chaos may be the result in which all parties suffer financial loss\, impaired reputations and environmental dam age.VIRTUAL SEMINAR COST : Single delegate  |  R1 750.00Multiple dele gates (2 or more)  |  R1 500.00One day webinar from 13h00 -16h00Time s hows in JohannesburgEARN CPD CREDITS!  TOTAL OF 7 HOURS(Each session: 3 hours and 1 hour for quiz completion)*PLEASE NOTE: Register with the ema il address that you will use to access the webinar on the day of the sessi ons.*/*! elementor - v3.10.2 - 29-01-2023 */.elementor-column .elementor-s pacer-inner{height:var(--spacer-size)}.e-con{--container-widget-width:100% }.e-con-inner>.elementor-widget-spacer\,.e-con>.elementor-widget-spacer{wi dth:var(--container-widget-width\,var(--spacer-size))\;--align-self:var(-- container-widget-align-self\,initial)\;--flex-shrink:0}.e-con-inner>.eleme ntor-widget-spacer>.elementor-widget-container\,.e-con-inner>.elementor-wi dget-spacer>.elementor-widget-container>.elementor-spacer\,.e-con>.element or-widget-spacer>.elementor-widget-container\,.e-con>.elementor-widget-spa cer>.elementor-widget-container>.elementor-spacer{height:100%}.e-con-inner >.elementor-widget-spacer>.elementor-widget-container>.elementor-spacer>.e lementor-spacer-inner\,.e-con>.elementor-widget-spacer>.elementor-widget-c ontainer>.elementor-spacer>.elementor-spacer-inner{height:var(--container- widget-height\,var(--spacer-size))}REGISTER HERE ATTACH;FMTTYPE=image/jpeg:https://jbcc.co.za/wp-content/uploads/2019/01/se rvices-3-960x600-1.jpeg END:VEVENT BEGIN:VEVENT UID:28@jbcc.co.za DTSTART;TZID=Africa/Johannesburg:20240213T130000 DTEND;TZID=Africa/Johannesburg:20240214T160000 DTSTAMP:20231209T183746Z URL:https://jbcc.co.za/events/jbcc-agreements-contracts-2018-2020-13-14-fe bruary-2024/ SUMMARY:JBCC AGREEMENTS/CONTRACTS 2018/2020 - 13-14 February 2024 DESCRIPTION:This is a training course conducted online using zoom presented in two sessions starting from 13h00 and ends at 16h00\nPresented by  – Professor Maritz\nObjectives:\nThe interpretation and understanding of th e JBCC agreements and contracts is fundamental in carrying out a successfu l construction project to final completion stage. Many projects stand stil l due the lack of contract knowledge in implementation. It is crucial that contracting parties adhere and fully understand the JBCC clauses before e ntering a JBCC agreement. This webinar reviews the JBCC clauses from imple mentation of a project to the final completion stages and gives a view to the delegates the challenges that might be experienced in progamme stages\ , remedies that can be used and what to avoid when administering a project using the JBCC agreements.\n\n\n\nLearning Outcomes:\n\n Describe the de velopment of the various types of building contracts in use in South Afric a\;\n Identify the important role of the JBCC documents in the South Afri can building industry\;\n Have an in-depth understanding of the historica l background and structure of the JBCC May 2018 6.2nd Ed\;\n Know what th e JBCC documents comprise of and its application in the South African buil ding industry and elsewhere in Africa\;\n Know what the duties are of the Principal Agent arising from the JBCC documents\; and\n Understand the m echanisms and day-to-day use of a selection of commonly encountered provis ions.\n\n\n\n\nSESSION 1\n\n Construction Law\n Pre-Contract Activities\ n Risk Management Procurement / Contract Data\n Dispute Resolution\nMedi ation\nAdjudication\nArbitration\n Definitions\n Offer and Acceptance Do cuments\n Agents/ Design Duties of the Parties\n Subcontractors\n\nSESSI ON 2\n\n Contract Instructions\n Execution &\; Completion Penalties ( Damages)\n Payments\n Adjustment of the Contract Value\n Insurances &am p\; Securities\n Suspension &\; Termination\n Differences between edi tions 4.1\, 6. 1 and 6.2\n State Contract Data\n New Contracts (SSWC &am p\; DCC)\n\n\n\n\nWho Can Attend:\n\n Principal Agents and Project Manage rs\n Architects\n Quantity Surveyors\n Engineers\n Building Contractor s and Subcontractors\n Employers\n Building Owners\, Developers\n Procu rement Officers\n Project Financiers\n Legal Advisors\n\n\n\n\nVIRTUAL S EMINAR COST (FOR BOTH SESSIONS): \nSingle delegate  |  R3 825.00\nMul tiple delegates (2 or more)  |  R3 385.00\n\nSession 1: November 15\, 2023 01:00 PM   |  Session 2: November 16\, 2023 01:00 PM\n\nTime sh ows in Johannesburg\n\nEARN CPD CREDITS!  TOTAL OF 7 HOURS\n(Each sessi on: 3 hours and 1 hour for quiz completion)\n*PLEASE NOTE: Register with the email address that you will use to access the webinar on the day of th e sessions.*\n \n\n REGISTER HERE\n ATTACH;FMTTYPE=image/jpeg:https://jbcc.co.za/wp-content/uploads/2019/01/se rvices-3-960x600-1.jpeg END:VEVENT BEGIN:VEVENT UID:23@jbcc.co.za DTSTART;TZID=Africa/Johannesburg:20240220T130000 DTEND;TZID=Africa/Johannesburg:20240220T160000 DTSTAMP:20231209T180025Z URL:https://jbcc.co.za/events/extension-of-time-and-role-of-the-principal- agent-webinar-20-february-2024/ SUMMARY:EXTENSION OF TIME AND ROLE OF THE PRINCIPAL AGENT WEBINAR - 20 Febr uary 2024 DESCRIPTION:JBCC MAY 2018 6TH EDITION: CLAUSE 23.0\nGUIDELINES ON HOW TO AD MINISTER EXTENSION OF TIME FOR PRACTICAL COMPLETION\nPresented by – Prof essor Maritz &\; Gerard Damstra\n\n/*! elementor - v3.10.2 - 29-01-2023 */.elementor-widget-divider{--divider-border-style:none\;--divider-border -width:1px\;--divider-color:#2c2c2c\;--divider-icon-size:20px\;--divider-e lement-spacing:10px\;--divider-pattern-height:24px\;--divider-pattern-size :20px\;--divider-pattern-url:none\;--divider-pattern-repeat:repeat-x}.elem entor-widget-divider .elementor-divider{display:flex}.elementor-widget-div ider .elementor-divider__text{font-size:15px\;line-height:1\;max-width:95% }.elementor-widget-divider .elementor-divider__element{margin:0 var(--divi der-element-spacing)\;flex-shrink:0}.elementor-widget-divider .elementor-i con{font-size:var(--divider-icon-size)}.elementor-widget-divider .elemento r-divider-separator{display:flex\;margin:0\;direction:ltr}.elementor-widge t-divider--view-line_icon .elementor-divider-separator\,.elementor-widget- divider--view-line_text .elementor-divider-separator{align-items:center}.e lementor-widget-divider--view-line_icon .elementor-divider-separator:after \,.elementor-widget-divider--view-line_icon .elementor-divider-separator:b efore\,.elementor-widget-divider--view-line_text .elementor-divider-separa tor:after\,.elementor-widget-divider--view-line_text .elementor-divider-se parator:before{display:block\;content:""\;border-bottom:0\;flex-grow:1\;bo rder-top:var(--divider-border-width) var(--divider-border-style) var(--div ider-color)}.elementor-widget-divider--element-align-left .elementor-divid er .elementor-divider-separator>.elementor-divider__svg:first-of-type{flex -grow:0\;flex-shrink:100}.elementor-widget-divider--element-align-left .el ementor-divider-separator:before{content:none}.elementor-widget-divider--e lement-align-left .elementor-divider__element{margin-left:0}.elementor-wid get-divider--element-align-right .elementor-divider .elementor-divider-sep arator>.elementor-divider__svg:last-of-type{flex-grow:0\;flex-shrink:100}. elementor-widget-divider--element-align-right .elementor-divider-separator :after{content:none}.elementor-widget-divider--element-align-right .elemen tor-divider__element{margin-right:0}.elementor-widget-divider:not(.element or-widget-divider--view-line_text):not(.elementor-widget-divider--view-lin e_icon) .elementor-divider-separator{border-top:var(--divider-border-width ) var(--divider-border-style) var(--divider-color)}.elementor-widget-divid er--separator-type-pattern{--divider-border-style:none}.elementor-widget-d ivider--separator-type-pattern.elementor-widget-divider--view-line .elemen tor-divider-separator\,.elementor-widget-divider--separator-type-pattern:n ot(.elementor-widget-divider--view-line) .elementor-divider-separator:afte r\,.elementor-widget-divider--separator-type-pattern:not(.elementor-widget -divider--view-line) .elementor-divider-separator:before\,.elementor-widge t-divider--separator-type-pattern:not([class*=elementor-widget-divider--vi ew]) .elementor-divider-separator{width:100%\;min-height:var(--divider-pat tern-height)\;-webkit-mask-size:var(--divider-pattern-size) 100%\;mask-siz e:var(--divider-pattern-size) 100%\;-webkit-mask-repeat:var(--divider-patt ern-repeat)\;mask-repeat:var(--divider-pattern-repeat)\;background-color:v ar(--divider-color)\;-webkit-mask-image:var(--divider-pattern-url)\;mask-i mage:var(--divider-pattern-url)}.elementor-widget-divider--no-spacing{--di vider-pattern-size:auto}.elementor-widget-divider--bg-round{--divider-patt ern-repeat:round}.rtl .elementor-widget-divider .elementor-divider__text{d irection:rtl}.e-con-inner>.elementor-widget-divider\,.e-con>.elementor-wid get-divider{width:var(--container-widget-width)\;--flex-grow:var(--contain er-widget-flex-grow)}\n\nSESSION 1\nJBCC May 2018 6th Edition: Clause 23.0 Guidelines on How to Administer Extension of Time for Practical Completio n\n\nPresenter: Professor Maritz\n\n• Delays where the contractor is not at fault would normally constitute a valid claim for (EOT).\n• Delays a ffects critical path of projects.\n• Confirming a delay and/ or disrupti on is not an easy task: it is a time-consuming process\, especially in mul tifaceted projects with thousands of activities\, a lot of details\, as we ll as the involvement of many stakeholders.\n• It is important for clien ts\, contractors\, sub-contractors\, and consultants to understand the fun damental requirements of compiling a successful EOT claim\, and the adjudi cation of claims submitted.\n• These training notes will provide those i nvolved in the preparation and adjudication of EOT claims under the JBCC w ith some essential information to deal more productively with this complex matter.\n• On larger projects\, the magnitude of time-related costs can easily run into millions of rand. With so much at stake\, it is understan dable that delay claims are a major source of disputes in the construction industry.\n• The proper assessment of delay claims is essential so that the parties can deal with it without having to resolve the dispute in exp ensive and drawn-out arbitration or litigation processes.\n\nSESSION 2\n\n JBCC MAY 2018 6th Edition: Understanding The Roles of The Various Role Pla yers Involved in The Building Contract with Emphasis on The Role of The Pr incipal Agent\n\nPresenter: Gerard Damstra\n\n• The building contract in volves a host of role players to establish a successful project - role pla yers all have specific functions to be performed within specific boundarie s\, with specific powers entrusted to them.\n• Role players must work to gether to ensure a successful project is completed within timeframes and w ith professionalism\, integrity\, honesty and moral standards.\n• Some f unctions are regulated by contracts between role players\, but others are governed by the standards laid down by society – the so-called boni more s of a community.\n• Role players must be aware of the impact of their a ctions.\n• It is imperative that all parties involved in a project have proper detailed knowledge of their respective roles\, powers\, duties\, ti melines and application of specialised professional contributions to the “team.”\n• It is the function of the principal agent to bring all th e aspects\, required for a successful building project\, together in a coo rdinated and orderly manner.\n• The role of the principal agent therefor e requires a proper understanding or else a project may fall apart to the detriment of all parties involved.\n• If the role of the principal agent is not fully understood\, chaos may be the result in which all parties su ffer financial loss\, impaired reputations and environmental damage.\nVIRT UAL SEMINAR COST : \nSingle delegate  |  R1 875.00\nMultiple delegate s (2 or more)  |  R1 770.00\n\nOne day webinar from 13h00 -16h00\n\nTi me shows in Johannesburg\n\nEARN CPD CREDITS!  TOTAL OF 7 HOURS\n(Each session: 3 hours and 1 hour for quiz completion)\n*PLEASE NOTE: Register with the email address that you will use to access the webinar on the day of the sessions.*\n/*! elementor - v3.10.2 - 29-01-2023 */.elementor-colum n .elementor-spacer-inner{height:var(--spacer-size)}.e-con{--container-wid get-width:100%}.e-con-inner>.elementor-widget-spacer\,.e-con>.elementor-wi dget-spacer{width:var(--container-widget-width\,var(--spacer-size))\;--ali gn-self:var(--container-widget-align-self\,initial)\;--flex-shrink:0}.e-co n-inner>.elementor-widget-spacer>.elementor-widget-container\,.e-con-inner >.elementor-widget-spacer>.elementor-widget-container>.elementor-spacer\,. e-con>.elementor-widget-spacer>.elementor-widget-container\,.e-con>.elemen tor-widget-spacer>.elementor-widget-container>.elementor-spacer{height:100 %}.e-con-inner>.elementor-widget-spacer>.elementor-widget-container>.eleme ntor-spacer>.elementor-spacer-inner\,.e-con>.elementor-widget-spacer>.elem entor-widget-container>.elementor-spacer>.elementor-spacer-inner{height:va r(--container-widget-height\,var(--spacer-size))}\n\n\nREGISTER HERE\n ATTACH;FMTTYPE=image/jpeg:https://jbcc.co.za/wp-content/uploads/2019/01/se rvices-3-960x600-1.jpeg END:VEVENT BEGIN:VEVENT UID:29@jbcc.co.za DTSTART;TZID=Africa/Johannesburg:20240312T130000 DTEND;TZID=Africa/Johannesburg:20240313T160000 DTSTAMP:20240201T102432Z URL:https://jbcc.co.za/events/jbcc-agreements-contracts-2018-2020-12013-ma rch-2024/ SUMMARY:JBCC AGREEMENTS/CONTRACTS 2018/2020 - 12-13 March 2024 DESCRIPTION:This is a training course conducted online using zoom presented in two sessions starting from 13h00 and ends at 16h00Presented by  – P rofessor MaritzObjectives:The interpretation and understanding of the JBCC agreements and contracts is fundamental in carrying out a successful cons truction project to final completion stage. Many projects stand still due the lack of contract knowledge in implementation. It is crucial that contr acting parties adhere and fully understand the JBCC clauses before enterin g a JBCC agreement. This webinar reviews the JBCC clauses from implementat ion of a project to the final completion stages and gives a view to the de legates the challenges that might be experienced in progamme stages\, reme dies that can be used and what to avoid when administering a project using the JBCC agreements.Learning Outcomes:Describe the development of the var ious types of building contracts in use in South Africa\;Identify the impo rtant role of the JBCC documents in the South African building industry\;H ave an in-depth understanding of the historical background and structure o f the JBCC May 2018 6.2nd Ed\;Know what the JBCC documents comprise of and its application in the South African building industry and elsewhere in A frica\;Know what the duties are of the Principal Agent arising from the JB CC documents\; andUnderstand the mechanisms and day-to-day use of a select ion of commonly encountered provisions.SESSION 1Construction LawPre-Contra ct ActivitiesRisk Management Procurement / Contract DataDispute Resolution MediationAdjudicationArbitrationDefinitionsOffer and Acceptance DocumentsA gents/ Design Duties of the PartiesSubcontractorsSESSION 2Contract Instruc tionsExecution &\; Completion Penalties (Damages)PaymentsAdjustment of the Contract ValueInsurances &\; SecuritiesSuspension &\; Terminatio nDifferences between editions 4.1\, 6. 1 and 6.2State Contract DataNew Con tracts (SSWC &\; DCC)Who Can Attend:Principal Agents and Project Manage rsArchitectsQuantity SurveyorsEngineersBuilding Contractors and Subcontrac torsEmployersBuilding Owners\, DevelopersProcurement OfficersProject Finan ciersLegal AdvisorsVIRTUAL SEMINAR COST (FOR BOTH SESSIONS): Single deleg ate  |  R3 825.00Multiple delegates (2 or more)  |  R3 385.00Sessi on 1: March 12\, 2024 01:00 PM   |  Session 2: March 13\, 2024 01:00 P MTime shows in JohannesburgEARN CPD CREDITS!  TOTAL OF 7 HOURS(Each ses sion: 3 hours and 1 hour for quiz completion)*PLEASE NOTE: Register with the email address that you will use to access the webinar on the day of th e sessions.* REGISTER HERE ATTACH;FMTTYPE=image/jpeg:https://jbcc.co.za/wp-content/uploads/2019/01/se rvices-3-960x600-1.jpeg END:VEVENT BEGIN:VEVENT UID:24@jbcc.co.za DTSTART;TZID=Africa/Johannesburg:20240326T130000 DTEND;TZID=Africa/Johannesburg:20240326T160000 DTSTAMP:20240306T131911Z URL:https://jbcc.co.za/events/extension-of-time-and-role-of-the-principal- agent-webinar-27-mar-2024/ SUMMARY:EXTENSION OF TIME AND ROLE OF THE PRINCIPAL AGENT WEBINAR - 26 Marc h 2024 DESCRIPTION:JBCC MAY 2018 6TH EDITION: CLAUSE 23.0\nGUIDELINES ON HOW TO AD MINISTER EXTENSION OF TIME FOR PRACTICAL COMPLETION\nPresented by – Prof essor Maritz &\; Gerard Damstra\n\n/*! elementor - v3.10.2 - 29-01-2023 */.elementor-widget-divider{--divider-border-style:none\;--divider-border -width:1px\;--divider-color:#2c2c2c\;--divider-icon-size:20px\;--divider-e lement-spacing:10px\;--divider-pattern-height:24px\;--divider-pattern-size :20px\;--divider-pattern-url:none\;--divider-pattern-repeat:repeat-x}.elem entor-widget-divider .elementor-divider{display:flex}.elementor-widget-div ider .elementor-divider__text{font-size:15px\;line-height:1\;max-width:95% }.elementor-widget-divider .elementor-divider__element{margin:0 var(--divi der-element-spacing)\;flex-shrink:0}.elementor-widget-divider .elementor-i con{font-size:var(--divider-icon-size)}.elementor-widget-divider .elemento r-divider-separator{display:flex\;margin:0\;direction:ltr}.elementor-widge t-divider--view-line_icon .elementor-divider-separator\,.elementor-widget- divider--view-line_text .elementor-divider-separator{align-items:center}.e lementor-widget-divider--view-line_icon .elementor-divider-separator:after \,.elementor-widget-divider--view-line_icon .elementor-divider-separator:b efore\,.elementor-widget-divider--view-line_text .elementor-divider-separa tor:after\,.elementor-widget-divider--view-line_text .elementor-divider-se parator:before{display:block\;content:""\;border-bottom:0\;flex-grow:1\;bo rder-top:var(--divider-border-width) var(--divider-border-style) var(--div ider-color)}.elementor-widget-divider--element-align-left .elementor-divid er .elementor-divider-separator>.elementor-divider__svg:first-of-type{flex -grow:0\;flex-shrink:100}.elementor-widget-divider--element-align-left .el ementor-divider-separator:before{content:none}.elementor-widget-divider--e lement-align-left .elementor-divider__element{margin-left:0}.elementor-wid get-divider--element-align-right .elementor-divider .elementor-divider-sep arator>.elementor-divider__svg:last-of-type{flex-grow:0\;flex-shrink:100}. elementor-widget-divider--element-align-right .elementor-divider-separator :after{content:none}.elementor-widget-divider--element-align-right .elemen tor-divider__element{margin-right:0}.elementor-widget-divider:not(.element or-widget-divider--view-line_text):not(.elementor-widget-divider--view-lin e_icon) .elementor-divider-separator{border-top:var(--divider-border-width ) var(--divider-border-style) var(--divider-color)}.elementor-widget-divid er--separator-type-pattern{--divider-border-style:none}.elementor-widget-d ivider--separator-type-pattern.elementor-widget-divider--view-line .elemen tor-divider-separator\,.elementor-widget-divider--separator-type-pattern:n ot(.elementor-widget-divider--view-line) .elementor-divider-separator:afte r\,.elementor-widget-divider--separator-type-pattern:not(.elementor-widget -divider--view-line) .elementor-divider-separator:before\,.elementor-widge t-divider--separator-type-pattern:not([class*=elementor-widget-divider--vi ew]) .elementor-divider-separator{width:100%\;min-height:var(--divider-pat tern-height)\;-webkit-mask-size:var(--divider-pattern-size) 100%\;mask-siz e:var(--divider-pattern-size) 100%\;-webkit-mask-repeat:var(--divider-patt ern-repeat)\;mask-repeat:var(--divider-pattern-repeat)\;background-color:v ar(--divider-color)\;-webkit-mask-image:var(--divider-pattern-url)\;mask-i mage:var(--divider-pattern-url)}.elementor-widget-divider--no-spacing{--di vider-pattern-size:auto}.elementor-widget-divider--bg-round{--divider-patt ern-repeat:round}.rtl .elementor-widget-divider .elementor-divider__text{d irection:rtl}.e-con-inner>.elementor-widget-divider\,.e-con>.elementor-wid get-divider{width:var(--container-widget-width)\;--flex-grow:var(--contain er-widget-flex-grow)}\n\nSESSION 1\nJBCC May 2018 6th Edition: Clause 23.0 Guidelines on How to Administer Extension of Time for Practical Completio n\n\nPresenter: Professor Maritz\n\n• Delays where the contractor is not at fault would normally constitute a valid claim for (EOT).\n• Delays a ffects critical path of projects.\n• Confirming a delay and/ or disrupti on is not an easy task: it is a time-consuming process\, especially in mul tifaceted projects with thousands of activities\, a lot of details\, as we ll as the involvement of many stakeholders.\n• It is important for clien ts\, contractors\, sub-contractors\, and consultants to understand the fun damental requirements of compiling a successful EOT claim\, and the adjudi cation of claims submitted.\n• These training notes will provide those i nvolved in the preparation and adjudication of EOT claims under the JBCC w ith some essential information to deal more productively with this complex matter.\n• On larger projects\, the magnitude of time-related costs can easily run into millions of rand. With so much at stake\, it is understan dable that delay claims are a major source of disputes in the construction industry.\n• The proper assessment of delay claims is essential so that the parties can deal with it without having to resolve the dispute in exp ensive and drawn-out arbitration or litigation processes.\n\nSESSION 2\n\n JBCC MAY 2018 6th Edition: Understanding The Roles of The Various Role Pla yers Involved in The Building Contract with Emphasis on The Role of The Pr incipal Agent\n\nPresenter: Gerard Damstra\n\n• The building contract in volves a host of role players to establish a successful project - role pla yers all have specific functions to be performed within specific boundarie s\, with specific powers entrusted to them.\n• Role players must work to gether to ensure a successful project is completed within timeframes and w ith professionalism\, integrity\, honesty and moral standards.\n• Some f unctions are regulated by contracts between role players\, but others are governed by the standards laid down by society – the so-called boni more s of a community.\n• Role players must be aware of the impact of their a ctions.\n• It is imperative that all parties involved in a project have proper detailed knowledge of their respective roles\, powers\, duties\, ti melines and application of specialised professional contributions to the “team.”\n• It is the function of the principal agent to bring all th e aspects\, required for a successful building project\, together in a coo rdinated and orderly manner.\n• The role of the principal agent therefor e requires a proper understanding or else a project may fall apart to the detriment of all parties involved.\n• If the role of the principal agent is not fully understood\, chaos may be the result in which all parties su ffer financial loss\, impaired reputations and environmental damage.\nVIRT UAL SEMINAR COST : \nSingle delegate  |  R1 875.00\nMultiple delegate s (2 or more)  |  R1 770.00\n\nOne day webinar from 13h00 -16h00\n\nTi me shows in Johannesburg\n\nEARN CPD CREDITS!  TOTAL OF 7 HOURS\n(Each session: 3 hours and 1 hour for quiz completion)\n*PLEASE NOTE: Register with the email address that you will use to access the webinar on the day of the sessions.*\n/*! elementor - v3.10.2 - 29-01-2023 */.elementor-colum n .elementor-spacer-inner{height:var(--spacer-size)}.e-con{--container-wid get-width:100%}.e-con-inner>.elementor-widget-spacer\,.e-con>.elementor-wi dget-spacer{width:var(--container-widget-width\,var(--spacer-size))\;--ali gn-self:var(--container-widget-align-self\,initial)\;--flex-shrink:0}.e-co n-inner>.elementor-widget-spacer>.elementor-widget-container\,.e-con-inner >.elementor-widget-spacer>.elementor-widget-container>.elementor-spacer\,. e-con>.elementor-widget-spacer>.elementor-widget-container\,.e-con>.elemen tor-widget-spacer>.elementor-widget-container>.elementor-spacer{height:100 %}.e-con-inner>.elementor-widget-spacer>.elementor-widget-container>.eleme ntor-spacer>.elementor-spacer-inner\,.e-con>.elementor-widget-spacer>.elem entor-widget-container>.elementor-spacer>.elementor-spacer-inner{height:va r(--container-widget-height\,var(--spacer-size))}\n\n\nREGISTER HERE\n ATTACH;FMTTYPE=image/jpeg:https://jbcc.co.za/wp-content/uploads/2019/01/se rvices-3-960x600-1.jpeg END:VEVENT BEGIN:VEVENT UID:30@jbcc.co.za DTSTART;TZID=Africa/Johannesburg:20240416T130000 DTEND;TZID=Africa/Johannesburg:20240417T160000 DTSTAMP:20240201T104026Z URL:https://jbcc.co.za/events/jbcc-agreements-contracts-2018-2020-16-17-ap ril-2024/ SUMMARY:JBCC AGREEMENTS/CONTRACTS 2018/2020 - 16-17 April 2024 DESCRIPTION:This is a training course conducted online using zoom presented in two sessions starting from 13h00 and ends at 16h00Presented by  – P rofessor MaritzObjectives:The interpretation and understanding of the JBCC agreements and contracts is fundamental in carrying out a successful cons truction project to final completion stage. Many projects stand still due the lack of contract knowledge in implementation. It is crucial that contr acting parties adhere and fully understand the JBCC clauses before enterin g a JBCC agreement. This webinar reviews the JBCC clauses from implementat ion of a project to the final completion stages and gives a view to the de legates the challenges that might be experienced in progamme stages\, reme dies that can be used and what to avoid when administering a project using the JBCC agreements.Learning Outcomes:Describe the development of the var ious types of building contracts in use in South Africa\;Identify the impo rtant role of the JBCC documents in the South African building industry\;H ave an in-depth understanding of the historical background and structure o f the JBCC May 2018 6.2nd Ed\;Know what the JBCC documents comprise of and its application in the South African building industry and elsewhere in A frica\;Know what the duties are of the Principal Agent arising from the JB CC documents\; andUnderstand the mechanisms and day-to-day use of a select ion of commonly encountered provisions.SESSION 1Construction LawPre-Contra ct ActivitiesRisk Management Procurement / Contract DataDispute Resolution MediationAdjudicationArbitrationDefinitionsOffer and Acceptance DocumentsA gents/ Design Duties of the PartiesSubcontractorsSESSION 2Contract Instruc tionsExecution &\; Completion Penalties (Damages)PaymentsAdjustment of the Contract ValueInsurances &\; SecuritiesSuspension &\; Terminatio nDifferences between editions 4.1\, 6. 1 and 6.2State Contract DataNew Con tracts (SSWC &\; DCC)Who Can Attend:Principal Agents and Project Manage rsArchitectsQuantity SurveyorsEngineersBuilding Contractors and Subcontrac torsEmployersBuilding Owners\, DevelopersProcurement OfficersProject Finan ciersLegal AdvisorsVIRTUAL SEMINAR COST (FOR BOTH SESSIONS): Single deleg ate  |  R3 825.00Multiple delegates (2 or more)  |  R3 385.00Sessi on 1: April 16\, 2024 01:00 PM   |  Session 2: April 17\, 2023 01:00 P MTime shows in JohannesburgEARN CPD CREDITS!  TOTAL OF 7 HOURS(Each ses sion: 3 hours and 1 hour for quiz completion)*PLEASE NOTE: Register with the email address that you will use to access the webinar on the day of th e sessions.* REGISTER HERE ATTACH;FMTTYPE=image/jpeg:https://jbcc.co.za/wp-content/uploads/2019/01/se rvices-3-960x600-1.jpeg END:VEVENT BEGIN:VEVENT UID:26@jbcc.co.za DTSTART;TZID=Africa/Johannesburg:20240515T130000 DTEND;TZID=Africa/Johannesburg:20240515T160000 DTSTAMP:20240508T061444Z URL:https://jbcc.co.za/events/extension-of-time-and-role-of-the-principal- agent-webinar-15-may-2024/ SUMMARY:EXTENSION OF TIME AND ROLE OF THE PRINCIPAL AGENT WEBINAR - 15 May 2024 DESCRIPTION:JBCC MAY 2018 6TH EDITION: CLAUSE 23.0GUIDELINES ON HOW TO ADMI NISTER EXTENSION OF TIME FOR PRACTICAL COMPLETIONPresented by – Professo r Maritz &\; Gerard Damstra/*! elementor - v3.10.2 - 29-01-2023 */.elem entor-widget-divider{--divider-border-style:none\;--divider-border-width:1 px\;--divider-color:#2c2c2c\;--divider-icon-size:20px\;--divider-element-s pacing:10px\;--divider-pattern-height:24px\;--divider-pattern-size:20px\;- -divider-pattern-url:none\;--divider-pattern-repeat:repeat-x}.elementor-wi dget-divider .elementor-divider{display:flex}.elementor-widget-divider .el ementor-divider__text{font-size:15px\;line-height:1\;max-width:95%}.elemen tor-widget-divider .elementor-divider__element{margin:0 var(--divider-elem ent-spacing)\;flex-shrink:0}.elementor-widget-divider .elementor-icon{font -size:var(--divider-icon-size)}.elementor-widget-divider .elementor-divide r-separator{display:flex\;margin:0\;direction:ltr}.elementor-widget-divide r--view-line_icon .elementor-divider-separator\,.elementor-widget-divider- -view-line_text .elementor-divider-separator{align-items:center}.elementor -widget-divider--view-line_icon .elementor-divider-separator:after\,.eleme ntor-widget-divider--view-line_icon .elementor-divider-separator:before\,. elementor-widget-divider--view-line_text .elementor-divider-separator:afte r\,.elementor-widget-divider--view-line_text .elementor-divider-separator: before{display:block\;content:""\;border-bottom:0\;flex-grow:1\;border-top :var(--divider-border-width) var(--divider-border-style) var(--divider-col or)}.elementor-widget-divider--element-align-left .elementor-divider .elem entor-divider-separator>.elementor-divider__svg:first-of-type{flex-grow:0\ ;flex-shrink:100}.elementor-widget-divider--element-align-left .elementor- divider-separator:before{content:none}.elementor-widget-divider--element-a lign-left .elementor-divider__element{margin-left:0}.elementor-widget-divi der--element-align-right .elementor-divider .elementor-divider-separator>. elementor-divider__svg:last-of-type{flex-grow:0\;flex-shrink:100}.elemento r-widget-divider--element-align-right .elementor-divider-separator:after{c ontent:none}.elementor-widget-divider--element-align-right .elementor-divi der__element{margin-right:0}.elementor-widget-divider:not(.elementor-widge t-divider--view-line_text):not(.elementor-widget-divider--view-line_icon) .elementor-divider-separator{border-top:var(--divider-border-width) var(-- divider-border-style) var(--divider-color)}.elementor-widget-divider--sepa rator-type-pattern{--divider-border-style:none}.elementor-widget-divider-- separator-type-pattern.elementor-widget-divider--view-line .elementor-divi der-separator\,.elementor-widget-divider--separator-type-pattern:not(.elem entor-widget-divider--view-line) .elementor-divider-separator:after\,.elem entor-widget-divider--separator-type-pattern:not(.elementor-widget-divider --view-line) .elementor-divider-separator:before\,.elementor-widget-divide r--separator-type-pattern:not([class*=elementor-widget-divider--view]) .el ementor-divider-separator{width:100%\;min-height:var(--divider-pattern-hei ght)\;-webkit-mask-size:var(--divider-pattern-size) 100%\;mask-size:var(-- divider-pattern-size) 100%\;-webkit-mask-repeat:var(--divider-pattern-repe at)\;mask-repeat:var(--divider-pattern-repeat)\;background-color:var(--div ider-color)\;-webkit-mask-image:var(--divider-pattern-url)\;mask-image:var (--divider-pattern-url)}.elementor-widget-divider--no-spacing{--divider-pa ttern-size:auto}.elementor-widget-divider--bg-round{--divider-pattern-repe at:round}.rtl .elementor-widget-divider .elementor-divider__text{direction :rtl}.e-con-inner>.elementor-widget-divider\,.e-con>.elementor-widget-divi der{width:var(--container-widget-width)\;--flex-grow:var(--container-widge t-flex-grow)}SESSION 1JBCC May 2018 6th Edition: Clause 23.0 Guidelines on How to Administer Extension of Time for Practical CompletionPresenter: Pr ofessor Maritz• Delays where the contractor is not at fault would normal ly constitute a valid claim for (EOT).• Delays affects critical path of projects.• Confirming a delay and/ or disruption is not an easy task: it is a time-consuming process\, especially in multifaceted projects with th ousands of activities\, a lot of details\, as well as the involvement of m any stakeholders.• It is important for clients\, contractors\, sub-contr actors\, and consultants to understand the fundamental requirements of com piling a successful EOT claim\, and the adjudication of claims submitted. • These training notes will provide those involved in the preparation an d adjudication of EOT claims under the JBCC with some essential informatio n to deal more productively with this complex matter.• On larger project s\, the magnitude of time-related costs can easily run into millions of ra nd. With so much at stake\, it is understandable that delay claims are a m ajor source of disputes in the construction industry.• The proper assess ment of delay claims is essential so that the parties can deal with it wit hout having to resolve the dispute in expensive and drawn-out arbitration or litigation processes.SESSION 2JBCC MAY 2018 6th Edition: Understanding The Roles of The Various Role Players Involved in The Building Contract wi th Emphasis on The Role of The Principal AgentPresenter: Gerard Damstra• The building contract involves a host of role players to establish a succ essful project - role players all have specific functions to be performed within specific boundaries\, with specific powers entrusted to them.• Ro le players must work together to ensure a successful project is completed within timeframes and with professionalism\, integrity\, honesty and moral standards.• Some functions are regulated by contracts between role play ers\, but others are governed by the standards laid down by society – th e so-called boni mores of a community.• Role players must be aware of th e impact of their actions.• It is imperative that all parties involved i n a project have proper detailed knowledge of their respective roles\, pow ers\, duties\, timelines and application of specialised professional contr ibutions to the “team.”• It is the function of the principal agent t o bring all the aspects\, required for a successful building project\, tog ether in a coordinated and orderly manner.• The role of the principal ag ent therefore requires a proper understanding or else a project may fall a part to the detriment of all parties involved.• If the role of the princ ipal agent is not fully understood\, chaos may be the result in which all parties suffer financial loss\, impaired reputations and environmental dam age.VIRTUAL SEMINAR COST : Single delegate  |  R1 875.00Multiple dele gates (2 or more)  |  R1 770.00One day webinar from 13h00 -16h00Time s hows in JohannesburgEARN CPD CREDITS!  TOTAL OF 7 HOURS(Each session: 3 hours and 1 hour for quiz completion)*PLEASE NOTE: Register with the ema il address that you will use to access the webinar on the day of the sessi ons.*/*! elementor - v3.10.2 - 29-01-2023 */.elementor-column .elementor-s pacer-inner{height:var(--spacer-size)}.e-con{--container-widget-width:100% }.e-con-inner>.elementor-widget-spacer\,.e-con>.elementor-widget-spacer{wi dth:var(--container-widget-width\,var(--spacer-size))\;--align-self:var(-- container-widget-align-self\,initial)\;--flex-shrink:0}.e-con-inner>.eleme ntor-widget-spacer>.elementor-widget-container\,.e-con-inner>.elementor-wi dget-spacer>.elementor-widget-container>.elementor-spacer\,.e-con>.element or-widget-spacer>.elementor-widget-container\,.e-con>.elementor-widget-spa cer>.elementor-widget-container>.elementor-spacer{height:100%}.e-con-inner >.elementor-widget-spacer>.elementor-widget-container>.elementor-spacer>.e lementor-spacer-inner\,.e-con>.elementor-widget-spacer>.elementor-widget-c ontainer>.elementor-spacer>.elementor-spacer-inner{height:var(--container- widget-height\,var(--spacer-size))}REGISTER HERE ATTACH;FMTTYPE=image/jpeg:https://jbcc.co.za/wp-content/uploads/2019/01/se rvices-3-960x600-1.jpeg END:VEVENT BEGIN:VEVENT UID:31@jbcc.co.za DTSTART;TZID=Africa/Johannesburg:20240521T130000 DTEND;TZID=Africa/Johannesburg:20240522T160000 DTSTAMP:20240201T104230Z URL:https://jbcc.co.za/events/jbcc-agreements-contracts-2018-2020-21-22-ma y-2024/ SUMMARY:JBCC AGREEMENTS/CONTRACTS 2018/2020 - 21-22 May 2024 DESCRIPTION:This is a training course conducted online using zoom presented in two sessions starting from 13h00 and ends at 16h00Presented by  – P rofessor MaritzObjectives:The interpretation and understanding of the JBCC agreements and contracts is fundamental in carrying out a successful cons truction project to final completion stage. Many projects stand still due the lack of contract knowledge in implementation. It is crucial that contr acting parties adhere and fully understand the JBCC clauses before enterin g a JBCC agreement. This webinar reviews the JBCC clauses from implementat ion of a project to the final completion stages and gives a view to the de legates the challenges that might be experienced in progamme stages\, reme dies that can be used and what to avoid when administering a project using the JBCC agreements.Learning Outcomes:Describe the development of the var ious types of building contracts in use in South Africa\;Identify the impo rtant role of the JBCC documents in the South African building industry\;H ave an in-depth understanding of the historical background and structure o f the JBCC May 2018 6.2nd Ed\;Know what the JBCC documents comprise of and its application in the South African building industry and elsewhere in A frica\;Know what the duties are of the Principal Agent arising from the JB CC documents\; andUnderstand the mechanisms and day-to-day use of a select ion of commonly encountered provisions.SESSION 1Construction LawPre-Contra ct ActivitiesRisk Management Procurement / Contract DataDispute Resolution MediationAdjudicationArbitrationDefinitionsOffer and Acceptance DocumentsA gents/ Design Duties of the PartiesSubcontractorsSESSION 2Contract Instruc tionsExecution &\; Completion Penalties (Damages)PaymentsAdjustment of the Contract ValueInsurances &\; SecuritiesSuspension &\; Terminatio nDifferences between editions 4.1\, 6. 1 and 6.2State Contract DataNew Con tracts (SSWC &\; DCC)Who Can Attend:Principal Agents and Project Manage rsArchitectsQuantity SurveyorsEngineersBuilding Contractors and Subcontrac torsEmployersBuilding Owners\, DevelopersProcurement OfficersProject Finan ciersLegal AdvisorsVIRTUAL SEMINAR COST (FOR BOTH SESSIONS): Single deleg ate  |  R3 825.00Multiple delegates (2 or more)  |  R3 385.00Sessi on 1: May 21\, 2024 01:00 PM   |  Session 2: May 22\, 2024 01:00 PMTime shows in JohannesburgEARN CPD CREDITS!  TOTAL OF 7 HOURS(Each session: 3 hours and 1 hour for quiz completion)*PLEASE NOTE: Register with the e mail address that you will use to access the webinar on the day of the ses sions.* REGISTER HERE ATTACH;FMTTYPE=image/jpeg:https://jbcc.co.za/wp-content/uploads/2019/01/se rvices-3-960x600-1.jpeg END:VEVENT BEGIN:VEVENT UID:34@jbcc.co.za DTSTART;TZID=Africa/Johannesburg:20240522T130000 DTEND;TZID=Africa/Johannesburg:20240523T163000 DTSTAMP:20240521T075151Z URL:https://jbcc.co.za/events/new-nssa-training-22-23-may-2024/ SUMMARY:NEW NSSA TRAINING - 22-23 May 2024 DESCRIPTION:The JBCC is bridging the gap with tailormade training to elevat e subcontractors with skills of administering and understanding JBCC contr acts.NEW NSSA TRAININGOur aim is to provide a clear overview and understan ding of the following topics:• The Law and its application to Constructi on• The importance of Standard Form Contracts\, with a focus on the JBCC • To successfully complete the NSSA Contract Data• To understand Preli minaries• An update on JBCC publications• To have and understanding of the JBCC N/S Subcontract Agreement with a focus on the following clauses: Presenter: Brad BoertjeAn expert in arbitration and adjudication\, having worked on more than 65 cases and affiliated with esteemed organizations li ke CAASA\, the Master Builders Association North\, ASAQS\, Brad has countl ess years of experience in building contacts.  He also sits behind numero us training programs\, having collaborated extensively with IOPSA.Led by a n industry expert\, this seminar guarantees insights and actionable strate gies to your contract administration skills.This is your opportunity to se cure your spot of construction knowledge. DATES : 22 May 2024 : 13:00 - 16:3023 May 2024 : 13:00 - 16:30Time shows in JohannesburgSingle delegate : R 2 200.00 incl.Multiple delegates: R2 090.00 incl.This is a virtual\, 2 day course.Click the link below to reserve your spot:REGISTER HEREDon't miss out on this opportunity ! Join us for a riveting seminar that promise s to fuel your success in the construction industry.TERMS &\; CONDITION S ATTACH;FMTTYPE=image/jpeg:https://jbcc.co.za/wp-content/uploads/2019/01/se rvices-3-960x600-1.jpeg END:VEVENT BEGIN:VEVENT UID:27@jbcc.co.za DTSTART;TZID=Africa/Johannesburg:20240612T130000 DTEND;TZID=Africa/Johannesburg:20240612T160000 DTSTAMP:20240201T104357Z URL:https://jbcc.co.za/events/extension-of-time-and-role-of-the-principal- agent-webinar-12-jun-2024/ SUMMARY:EXTENSION OF TIME AND ROLE OF THE PRINCIPAL AGENT WEBINAR - 12 Jun e 2024 DESCRIPTION:JBCC MAY 2018 6TH EDITION: CLAUSE 23.0GUIDELINES ON HOW TO ADMI NISTER EXTENSION OF TIME FOR PRACTICAL COMPLETIONPresented by – Professo r Maritz &\; Gerard Damstra/*! elementor - v3.10.2 - 29-01-2023 */.elem entor-widget-divider{--divider-border-style:none\;--divider-border-width:1 px\;--divider-color:#2c2c2c\;--divider-icon-size:20px\;--divider-element-s pacing:10px\;--divider-pattern-height:24px\;--divider-pattern-size:20px\;- -divider-pattern-url:none\;--divider-pattern-repeat:repeat-x}.elementor-wi dget-divider .elementor-divider{display:flex}.elementor-widget-divider .el ementor-divider__text{font-size:15px\;line-height:1\;max-width:95%}.elemen tor-widget-divider .elementor-divider__element{margin:0 var(--divider-elem ent-spacing)\;flex-shrink:0}.elementor-widget-divider .elementor-icon{font -size:var(--divider-icon-size)}.elementor-widget-divider .elementor-divide r-separator{display:flex\;margin:0\;direction:ltr}.elementor-widget-divide r--view-line_icon .elementor-divider-separator\,.elementor-widget-divider- -view-line_text .elementor-divider-separator{align-items:center}.elementor -widget-divider--view-line_icon .elementor-divider-separator:after\,.eleme ntor-widget-divider--view-line_icon .elementor-divider-separator:before\,. elementor-widget-divider--view-line_text .elementor-divider-separator:afte r\,.elementor-widget-divider--view-line_text .elementor-divider-separator: before{display:block\;content:""\;border-bottom:0\;flex-grow:1\;border-top :var(--divider-border-width) var(--divider-border-style) var(--divider-col or)}.elementor-widget-divider--element-align-left .elementor-divider .elem entor-divider-separator>.elementor-divider__svg:first-of-type{flex-grow:0\ ;flex-shrink:100}.elementor-widget-divider--element-align-left .elementor- divider-separator:before{content:none}.elementor-widget-divider--element-a lign-left .elementor-divider__element{margin-left:0}.elementor-widget-divi der--element-align-right .elementor-divider .elementor-divider-separator>. elementor-divider__svg:last-of-type{flex-grow:0\;flex-shrink:100}.elemento r-widget-divider--element-align-right .elementor-divider-separator:after{c ontent:none}.elementor-widget-divider--element-align-right .elementor-divi der__element{margin-right:0}.elementor-widget-divider:not(.elementor-widge t-divider--view-line_text):not(.elementor-widget-divider--view-line_icon) .elementor-divider-separator{border-top:var(--divider-border-width) var(-- divider-border-style) var(--divider-color)}.elementor-widget-divider--sepa rator-type-pattern{--divider-border-style:none}.elementor-widget-divider-- separator-type-pattern.elementor-widget-divider--view-line .elementor-divi der-separator\,.elementor-widget-divider--separator-type-pattern:not(.elem entor-widget-divider--view-line) .elementor-divider-separator:after\,.elem entor-widget-divider--separator-type-pattern:not(.elementor-widget-divider --view-line) .elementor-divider-separator:before\,.elementor-widget-divide r--separator-type-pattern:not([class*=elementor-widget-divider--view]) .el ementor-divider-separator{width:100%\;min-height:var(--divider-pattern-hei ght)\;-webkit-mask-size:var(--divider-pattern-size) 100%\;mask-size:var(-- divider-pattern-size) 100%\;-webkit-mask-repeat:var(--divider-pattern-repe at)\;mask-repeat:var(--divider-pattern-repeat)\;background-color:var(--div ider-color)\;-webkit-mask-image:var(--divider-pattern-url)\;mask-image:var (--divider-pattern-url)}.elementor-widget-divider--no-spacing{--divider-pa ttern-size:auto}.elementor-widget-divider--bg-round{--divider-pattern-repe at:round}.rtl .elementor-widget-divider .elementor-divider__text{direction :rtl}.e-con-inner>.elementor-widget-divider\,.e-con>.elementor-widget-divi der{width:var(--container-widget-width)\;--flex-grow:var(--container-widge t-flex-grow)}SESSION 1JBCC May 2018 6th Edition: Clause 23.0 Guidelines on How to Administer Extension of Time for Practical CompletionPresenter: Pr ofessor Maritz• Delays where the contractor is not at fault would normal ly constitute a valid claim for (EOT).• Delays affects critical path of projects.• Confirming a delay and/ or disruption is not an easy task: it is a time-consuming process\, especially in multifaceted projects with th ousands of activities\, a lot of details\, as well as the involvement of m any stakeholders.• It is important for clients\, contractors\, sub-contr actors\, and consultants to understand the fundamental requirements of com piling a successful EOT claim\, and the adjudication of claims submitted. • These training notes will provide those involved in the preparation an d adjudication of EOT claims under the JBCC with some essential informatio n to deal more productively with this complex matter.• On larger project s\, the magnitude of time-related costs can easily run into millions of ra nd. With so much at stake\, it is understandable that delay claims are a m ajor source of disputes in the construction industry.• The proper assess ment of delay claims is essential so that the parties can deal with it wit hout having to resolve the dispute in expensive and drawn-out arbitration or litigation processes.SESSION 2JBCC MAY 2018 6th Edition: Understanding The Roles of The Various Role Players Involved in The Building Contract wi th Emphasis on The Role of The Principal AgentPresenter: Gerard Damstra• The building contract involves a host of role players to establish a succ essful project - role players all have specific functions to be performed within specific boundaries\, with specific powers entrusted to them.• Ro le players must work together to ensure a successful project is completed within timeframes and with professionalism\, integrity\, honesty and moral standards.• Some functions are regulated by contracts between role play ers\, but others are governed by the standards laid down by society – th e so-called boni mores of a community.• Role players must be aware of th e impact of their actions.• It is imperative that all parties involved i n a project have proper detailed knowledge of their respective roles\, pow ers\, duties\, timelines and application of specialised professional contr ibutions to the “team.”• It is the function of the principal agent t o bring all the aspects\, required for a successful building project\, tog ether in a coordinated and orderly manner.• The role of the principal ag ent therefore requires a proper understanding or else a project may fall a part to the detriment of all parties involved.• If the role of the princ ipal agent is not fully understood\, chaos may be the result in which all parties suffer financial loss\, impaired reputations and environmental dam age.VIRTUAL SEMINAR COST : Single delegate  |  R1 875.00Multiple dele gates (2 or more)  |  R1 770.00One day webinar from 13h00 -16h00Time s hows in JohannesburgEARN CPD CREDITS!  TOTAL OF 7 HOURS(Each session: 3 hours and 1 hour for quiz completion)*PLEASE NOTE: Register with the ema il address that you will use to access the webinar on the day of the sessi ons.*/*! elementor - v3.10.2 - 29-01-2023 */.elementor-column .elementor-s pacer-inner{height:var(--spacer-size)}.e-con{--container-widget-width:100% }.e-con-inner>.elementor-widget-spacer\,.e-con>.elementor-widget-spacer{wi dth:var(--container-widget-width\,var(--spacer-size))\;--align-self:var(-- container-widget-align-self\,initial)\;--flex-shrink:0}.e-con-inner>.eleme ntor-widget-spacer>.elementor-widget-container\,.e-con-inner>.elementor-wi dget-spacer>.elementor-widget-container>.elementor-spacer\,.e-con>.element or-widget-spacer>.elementor-widget-container\,.e-con>.elementor-widget-spa cer>.elementor-widget-container>.elementor-spacer{height:100%}.e-con-inner >.elementor-widget-spacer>.elementor-widget-container>.elementor-spacer>.e lementor-spacer-inner\,.e-con>.elementor-widget-spacer>.elementor-widget-c ontainer>.elementor-spacer>.elementor-spacer-inner{height:var(--container- widget-height\,var(--spacer-size))}REGISTER HERE ATTACH;FMTTYPE=image/jpeg:https://jbcc.co.za/wp-content/uploads/2019/01/se rvices-3-960x600-1.jpeg END:VEVENT BEGIN:VEVENT UID:35@jbcc.co.za DTSTART;TZID=Africa/Johannesburg:20240619T130000 DTEND;TZID=Africa/Johannesburg:20240620T163000 DTSTAMP:20240524T114940Z URL:https://jbcc.co.za/events/new-nssa-training-19-20-june-2024/ SUMMARY:NEW NSSA TRAINING - 19-20 June 2024 DESCRIPTION:The JBCC is bridging the gap with tailormade training to elevat e subcontractors with skills of administering and understanding JBCC contr acts.\nNEW NSSA TRAINING\nOur aim is to provide a clear overview and under standing of the following topics:\n\n• The Law and its application to Co nstruction\n• The importance of Standard Form Contracts\, with a focus o n the JBCC\n• To successfully complete the NSSA Contract Data\n• To un derstand Preliminaries\n• An update on JBCC publications\n• To have an d understanding of the JBCC N/S Subcontract Agreement with a focus on the following clauses:\n\nPresenter: Brad Boertje\n\nAn expert in arbitration and adjudication\, having worked on more than 65 cases and affiliated with esteemed organizations like CAASA\, the Master Builders Association North \, ASAQS\, Brad has countless years of experience in building contacts.  He also sits behind numerous training programs\, having collaborated exten sively with IOPSA.\n\nLed by an industry expert\, this seminar guarantees insights and actionable strategies to your contract administration skills. \n\nThis is your opportunity to secure your spot of construction knowledge .\n\nDATES : \n19 June 2024 : 13:00 - 16:30\n20 June 2024 : 13:00 - 16:30 \n\nTime shows in Johannesburg\nSingle delegate : R 2 200.00 incl.\nMulti ple delegates: R2 090.00 incl.\n\nThis is a virtual\, 2 day course.\nClick the link below to reserve your spot:\nREGISTER HERE\nDon't miss out on th is opportunity ! Join us for a riveting seminar that promises to fuel your success in the construction industry.\nTERMS &\; CONDITIONS ATTACH;FMTTYPE=image/jpeg:https://jbcc.co.za/wp-content/uploads/2019/01/se rvices-3-960x600-1.jpeg END:VEVENT BEGIN:VEVENT UID:38@jbcc.co.za DTSTART;TZID=Africa/Johannesburg:20240717T130000 DTEND;TZID=Africa/Johannesburg:20240718T163000 DTSTAMP:20240718T131825Z URL:https://jbcc.co.za/events/new-nssa-training-17-18-july-2024/ SUMMARY:NSSA TRAINING - 17-18 July 2024 DESCRIPTION:The JBCC is bridging the gap with tailormade training to elevat e subcontractors with skills of administering and understanding JBCC contr acts.\nNEW NSSA TRAINING\nOur aim is to provide a clear overview and under standing of the following topics:\n\n• The Law and its application to Co nstruction\n• The importance of Standard Form Contracts\, with a focus o n the JBCC\n• To successfully complete the NSSA Contract Data\n• To un derstand Preliminaries\n• An update on JBCC publications\n• To have an d understanding of the JBCC N/S Subcontract Agreement with a focus on the following clauses:\n\nPresenter: Brad Boertje\n\nAn expert in arbitration and adjudication\, having worked on more than 65 cases and affiliated with esteemed organizations like CAASA\, the Master Builders Association North \, ASAQS\, Brad has countless years of experience in building contacts.  He also sits behind numerous training programs\, having collaborated exten sively with IOPSA.\n\nLed by an industry expert\, this seminar guarantees insights and actionable strategies to your contract administration skills. \n\nThis is your opportunity to secure your spot of construction knowledge .\n\nDATES : \n17 July 2024 : 13:00 - 16:30\n18 July 2024 : 13:00 - 16:30 \n\nTime shows in Johannesburg\nSingle delegate : R 2 200.00 incl.\nMulti ple delegates: R2 090.00 incl.\n\nThis is a virtual\, 2 day course.\nClick the link below to reserve your spot:\nREGISTER HERE\nDon't miss out on th is opportunity ! Join us for a riveting seminar that promises to fuel your success in the construction industry.\nTERMS &\; CONDITIONS ATTACH;FMTTYPE=image/jpeg:https://jbcc.co.za/wp-content/uploads/2019/01/se rvices-3-960x600-1.jpeg END:VEVENT BEGIN:VEVENT UID:37@jbcc.co.za DTSTART;TZID=Africa/Johannesburg:20240724T130000 DTEND;TZID=Africa/Johannesburg:20240725T160000 DTSTAMP:20240718T131831Z URL:https://jbcc.co.za/events/jbcc-agreements-contracts-2018-2020-24-25-ju ly-2024/ SUMMARY:JBCC AGREEMENTS/CONTRACTS 2018/2020 - 24-25 July 2024 DESCRIPTION:This is a training course conducted online using zoom presented in two sessions starting from 13h00 and ends at 16h00\nPresented by  – Gerard Damstra &\; Brad Boertje\nObjectives:\nThe interpretation and u nderstanding of the JBCC agreements and contracts is fundamental in carryi ng out a successful construction project to final completion stage. Many p rojects stand still due the lack of contract knowledge in implementation. It is crucial that contracting parties adhere and fully understand the JBC C clauses before entering a JBCC agreement. This webinar reviews the JBCC clauses from implementation of a project to the final completion stages an d gives a view to the delegates the challenges that might be experienced i n progamme stages\, remedies that can be used and what to avoid when admin istering a project using the JBCC agreements.\n\n\n\nLearning Outcomes:\n\ n Describe the development of the various types of building contracts in use in South Africa\;\n Identify the important role of the JBCC documents in the South African building industry\;\n Have an in-depth understandin g of the historical background and structure of the JBCC May 2018 6.2nd Ed \;\n Know what the JBCC documents comprise of and its application in the South African building industry and elsewhere in Africa\;\n Know what the duties are of the Principal Agent arising from the JBCC documents\; and\n Understand the mechanisms and day-to-day use of a selection of commonly encountered provisions.\n\n\n\n\nSESSION 1\n\n Construction Law\n Pre-Co ntract Activities\n Risk Management Procurement / Contract Data\n Disput e Resolution\nMediation\nAdjudication\nArbitration\n Definitions\n Offer and Acceptance Documents\n Agents/ Design Duties of the Parties\n Subco ntractors\n\nSESSION 2\n\n Contract Instructions\n Execution &\; Comp letion Penalties (Damages)\n Payments\n Adjustment of the Contract Value \n Insurances &\; Securities\n Suspension &\; Termination\n Diffe rences between editions 4.1\, 6. 1 and 6.2\n State Contract Data\n New C ontracts (SSWC &\; DCC)\n\n\n\n\nWho Can Attend:\n\n Principal Agents and Project Managers\n Architects\n Quantity Surveyors\n Engineers\n B uilding Contractors and Subcontractors\n Employers\n Building Owners\, D evelopers\n Procurement Officers\n Project Financiers\n Legal Advisors\ n\n\n\n\nVIRTUAL SEMINAR COST (FOR BOTH SESSIONS): \nSingle delegate  |   R3 825.00\nMultiple delegates (2 or more)  |  R3 385.00\n\nSession 1: July 24\, 2024 01:00 PM   |  Session 2:  July 25\, 2024 01:00 PM\n \nTime shows in Johannesburg\n\nEARN CPD CREDITS!  TOTAL OF 7 HOURS\n(E ach session: 3 hours and 1 hour for quiz completion)\n*PLEASE NOTE: Regis ter with the email address that you will use to access the webinar on the day of the sessions.*\n \n\n REGISTER HERE\n ATTACH;FMTTYPE=image/jpeg:https://jbcc.co.za/wp-content/uploads/2019/01/se rvices-3-960x600-1.jpeg END:VEVENT BEGIN:VEVENT UID:40@jbcc.co.za DTSTART;TZID=Africa/Johannesburg:20240814T130000 DTEND;TZID=Africa/Johannesburg:20240815T160000 DTSTAMP:20240805T064342Z URL:https://jbcc.co.za/events/jbcc-agreements-contracts-2018-2020-14-15-au gust-2024/ SUMMARY:JBCC AGREEMENTS/CONTRACTS 2018/2020 - 14-15 August 2024 DESCRIPTION:This is a training course conducted online using zoom presented in two sessions starting from 13h00 and ends at 16h00\nPresented by  – Gerard Damstra &\; Brad Boertje\nObjectives:\nThe interpretation and u nderstanding of the JBCC agreements and contracts is fundamental in carryi ng out a successful construction project to final completion stage. Many p rojects stand still due the lack of contract knowledge in implementation. It is crucial that contracting parties adhere and fully understand the JBC C clauses before entering a JBCC agreement. This webinar reviews the JBCC clauses from implementation of a project to the final completion stages an d gives a view to the delegates the challenges that might be experienced i n progamme stages\, remedies that can be used and what to avoid when admin istering a project using the JBCC agreements.\n\n\n\nLearning Outcomes:\n\ n Describe the development of the various types of building contracts in use in South Africa\;\n Identify the important role of the JBCC documents in the South African building industry\;\n Have an in-depth understandin g of the historical background and structure of the JBCC May 2018 6.2nd Ed \;\n Know what the JBCC documents comprise of and its application in the South African building industry and elsewhere in Africa\;\n Know what the duties are of the Principal Agent arising from the JBCC documents\; and\n Understand the mechanisms and day-to-day use of a selection of commonly encountered provisions.\n\n\n\n\nSESSION 1\n\n Construction Law\n Pre-Co ntract Activities\n Risk Management Procurement / Contract Data\n Disput e Resolution\nMediation\nAdjudication\nArbitration\n Definitions\n Offer and Acceptance Documents\n Agents/ Design Duties of the Parties\n Subco ntractors\n\nSESSION 2\n\n Contract Instructions\n Execution &\; Comp letion Penalties (Damages)\n Payments\n Adjustment of the Contract Value \n Insurances &\; Securities\n Suspension &\; Termination\n Diffe rences between editions 4.1\, 6. 1 and 6.2\n State Contract Data\n New C ontracts (SSWC &\; DCC)\n\n\n\n\nWho Can Attend:\n\n Principal Agents and Project Managers\n Architects\n Quantity Surveyors\n Engineers\n B uilding Contractors and Subcontractors\n Employers\n Building Owners\, D evelopers\n Procurement Officers\n Project Financiers\n Legal Advisors\ n\n\n\n\nVIRTUAL SEMINAR COST (FOR BOTH SESSIONS): \nSingle delegate  |   R3 825.00\nMultiple delegates (2 or more)  |  R3 385.00\n\nSession 1: 14 August 2024 01:00 PM   |  Session 2: 15 August 2024 01:00 PM\n\n Time shows in Johannesburg\n\nEARN CPD CREDITS!  TOTAL OF 7 HOURS\n(Eac h session: 3 hours and 1 hour for quiz completion)\n*PLEASE NOTE: Registe r with the email address that you will use to access the webinar on the da y of the sessions.*\n \n\n REGISTER HERE\n ATTACH;FMTTYPE=image/jpeg:https://jbcc.co.za/wp-content/uploads/2019/01/se rvices-3-960x600-1.jpeg END:VEVENT BEGIN:VEVENT UID:42@jbcc.co.za DTSTART;TZID=Africa/Johannesburg:20240821T130000 DTEND;TZID=Africa/Johannesburg:20240822T163000 DTSTAMP:20240805T064348Z URL:https://jbcc.co.za/events/new-nssa-training-21-22-august-2024/ SUMMARY:NSSA TRAINING - 21-22 August 2024 DESCRIPTION:The JBCC is bridging the gap with tailormade training to elevat e subcontractors with skills of administering and understanding JBCC contr acts.\nNEW NSSA TRAINING\nOur aim is to provide a clear overview and under standing of the following topics:\n\n• The Law and its application to Co nstruction\n• The importance of Standard Form Contracts\, with a focus o n the JBCC\n• To successfully complete the NSSA Contract Data\n• To un derstand Preliminaries\n• An update on JBCC publications\n• To have an d understanding of the JBCC N/S Subcontract Agreement with a focus on the following clauses:\n\nPresenter: Brad Boertje\n\nAn expert in arbitration and adjudication\, having worked on more than 65 cases and affiliated with esteemed organizations like CAASA\, the Master Builders Association North \, ASAQS\, Brad has countless years of experience in building contacts.  He also sits behind numerous training programs\, having collaborated exten sively with IOPSA.\n\nLed by an industry expert\, this seminar guarantees insights and actionable strategies to your contract administration skills. \n\nThis is your opportunity to secure your spot of construction knowledge .\n\nDATES : \n21 August 2024 : 13:00 - 16:30\n22 August 2024 : 13:00 - 1 6:30\n\nTime shows in Johannesburg\nSingle delegate : R 1 600.00 incl.\nM ultiple delegates: R1 520.00 incl.\n\nThis is a virtual\, 2 day course.\nC lick the link below to reserve your spot:\nREGISTER HERE\nDon't miss out o n this opportunity ! Join us for a riveting seminar that promises to fuel your success in the construction industry.\nTERMS &\; CONDITIONS ATTACH;FMTTYPE=image/jpeg:https://jbcc.co.za/wp-content/uploads/2019/01/se rvices-3-960x600-1.jpeg END:VEVENT BEGIN:VEVENT UID:39@jbcc.co.za DTSTART;TZID=Africa/Johannesburg:20240827T130000 DTEND;TZID=Africa/Johannesburg:20240827T160000 DTSTAMP:20240805T064355Z URL:https://jbcc.co.za/events/extension-of-time-and-role-of-the-principal- agent-webinar-27-august-2024/ SUMMARY:EXTENSION OF TIME AND ROLE OF THE PRINCIPAL AGENT WEBINAR - 27 Aug ust 2024 DESCRIPTION:JBCC MAY 2018 6TH EDITION: CLAUSE 23.0\nGUIDELINES ON HOW TO AD MINISTER EXTENSION OF TIME FOR PRACTICAL COMPLETION\nPresented by – Gera rd Damstra\n\n/*! elementor - v3.10.2 - 29-01-2023 */.elementor-widget-div ider{--divider-border-style:none\;--divider-border-width:1px\;--divider-co lor:#2c2c2c\;--divider-icon-size:20px\;--divider-element-spacing:10px\;--d ivider-pattern-height:24px\;--divider-pattern-size:20px\;--divider-pattern -url:none\;--divider-pattern-repeat:repeat-x}.elementor-widget-divider .el ementor-divider{display:flex}.elementor-widget-divider .elementor-divider_ _text{font-size:15px\;line-height:1\;max-width:95%}.elementor-widget-divid er .elementor-divider__element{margin:0 var(--divider-element-spacing)\;fl ex-shrink:0}.elementor-widget-divider .elementor-icon{font-size:var(--divi der-icon-size)}.elementor-widget-divider .elementor-divider-separator{disp lay:flex\;margin:0\;direction:ltr}.elementor-widget-divider--view-line_ico n .elementor-divider-separator\,.elementor-widget-divider--view-line_text .elementor-divider-separator{align-items:center}.elementor-widget-divider- -view-line_icon .elementor-divider-separator:after\,.elementor-widget-divi der--view-line_icon .elementor-divider-separator:before\,.elementor-widget -divider--view-line_text .elementor-divider-separator:after\,.elementor-wi dget-divider--view-line_text .elementor-divider-separator:before{display:b lock\;content:""\;border-bottom:0\;flex-grow:1\;border-top:var(--divider-b order-width) var(--divider-border-style) var(--divider-color)}.elementor-w idget-divider--element-align-left .elementor-divider .elementor-divider-se parator>.elementor-divider__svg:first-of-type{flex-grow:0\;flex-shrink:100 }.elementor-widget-divider--element-align-left .elementor-divider-separato r:before{content:none}.elementor-widget-divider--element-align-left .eleme ntor-divider__element{margin-left:0}.elementor-widget-divider--element-ali gn-right .elementor-divider .elementor-divider-separator>.elementor-divide r__svg:last-of-type{flex-grow:0\;flex-shrink:100}.elementor-widget-divider --element-align-right .elementor-divider-separator:after{content:none}.ele mentor-widget-divider--element-align-right .elementor-divider__element{mar gin-right:0}.elementor-widget-divider:not(.elementor-widget-divider--view- line_text):not(.elementor-widget-divider--view-line_icon) .elementor-divid er-separator{border-top:var(--divider-border-width) var(--divider-border-s tyle) var(--divider-color)}.elementor-widget-divider--separator-type-patte rn{--divider-border-style:none}.elementor-widget-divider--separator-type-p attern.elementor-widget-divider--view-line .elementor-divider-separator\,. elementor-widget-divider--separator-type-pattern:not(.elementor-widget-div ider--view-line) .elementor-divider-separator:after\,.elementor-widget-div ider--separator-type-pattern:not(.elementor-widget-divider--view-line) .el ementor-divider-separator:before\,.elementor-widget-divider--separator-typ e-pattern:not([class*=elementor-widget-divider--view]) .elementor-divider- separator{width:100%\;min-height:var(--divider-pattern-height)\;-webkit-ma sk-size:var(--divider-pattern-size) 100%\;mask-size:var(--divider-pattern- size) 100%\;-webkit-mask-repeat:var(--divider-pattern-repeat)\;mask-repeat :var(--divider-pattern-repeat)\;background-color:var(--divider-color)\;-we bkit-mask-image:var(--divider-pattern-url)\;mask-image:var(--divider-patte rn-url)}.elementor-widget-divider--no-spacing{--divider-pattern-size:auto} .elementor-widget-divider--bg-round{--divider-pattern-repeat:round}.rtl .e lementor-widget-divider .elementor-divider__text{direction:rtl}.e-con-inne r>.elementor-widget-divider\,.e-con>.elementor-widget-divider{width:var(-- container-widget-width)\;--flex-grow:var(--container-widget-flex-grow)}\n\ nSESSION 1\nJBCC May 2018 6th Edition: Clause 23.0 Guidelines on How to Ad minister Extension of Time for Practical Completion\n\nPresenter: Gerard D amstra\n\n• Delays where the contractor is not at fault would normally c onstitute a valid claim for (EOT).\n• Delays affects critical path of pr ojects.\n• Confirming a delay and/ or disruption is not an easy task: it is a time-consuming process\, especially in multifaceted projects with th ousands of activities\, a lot of details\, as well as the involvement of m any stakeholders.\n• It is important for clients\, contractors\, sub-con tractors\, and consultants to understand the fundamental requirements of c ompiling a successful EOT claim\, and the adjudication of claims submitted .\n• These training notes will provide those involved in the preparation and adjudication of EOT claims under the JBCC with some essential informa tion to deal more productively with this complex matter.\n• On larger pr ojects\, the magnitude of time-related costs can easily run into millions of rand. With so much at stake\, it is understandable that delay claims ar e a major source of disputes in the construction industry.\n• The proper assessment of delay claims is essential so that the parties can deal with it without having to resolve the dispute in expensive and drawn-out arbit ration or litigation processes.\n\nSESSION 2\n\nJBCC MAY 2018 6th Edition: Understanding The Roles of The Various Role Players Involved in The Build ing Contract with Emphasis on The Role of The Principal Agent\n\nPresenter : Gerard Damstra\n\n• The building contract involves a host of role play ers to establish a successful project - role players all have specific fun ctions to be performed within specific boundaries\, with specific powers e ntrusted to them.\n• Role players must work together to ensure a success ful project is completed within timeframes and with professionalism\, inte grity\, honesty and moral standards.\n• Some functions are regulated by contracts between role players\, but others are governed by the standards laid down by society – the so-called boni mores of a community.\n• Rol e players must be aware of the impact of their actions.\n• It is imperat ive that all parties involved in a project have proper detailed knowledge of their respective roles\, powers\, duties\, timelines and application of specialised professional contributions to the “team.”\n• It is the function of the principal agent to bring all the aspects\, required for a successful building project\, together in a coordinated and orderly manner .\n• The role of the principal agent therefore requires a proper underst anding or else a project may fall apart to the detriment of all parties in volved.\n• If the role of the principal agent is not fully understood\, chaos may be the result in which all parties suffer financial loss\, impai red reputations and environmental damage.\nVIRTUAL SEMINAR COST : \nSingl e delegate  |  R1 875.00\nMultiple delegates (2 or more)  |  R1 77 0.00\n\nOne day webinar from 13h00 -16h00\n\nTime shows in Johannesburg\n \nEARN CPD CREDITS!  TOTAL OF 7 HOURS\n(Each session: 3 hours and 1 hour for quiz completion)\n*PLEASE NOTE: Register with the email address that you will use to access the webinar on the day of the sessions.*\n/*! elem entor - v3.10.2 - 29-01-2023 */.elementor-column .elementor-spacer-inner{h eight:var(--spacer-size)}.e-con{--container-widget-width:100%}.e-con-inner >.elementor-widget-spacer\,.e-con>.elementor-widget-spacer{width:var(--con tainer-widget-width\,var(--spacer-size))\;--align-self:var(--container-wid get-align-self\,initial)\;--flex-shrink:0}.e-con-inner>.elementor-widget-s pacer>.elementor-widget-container\,.e-con-inner>.elementor-widget-spacer>. elementor-widget-container>.elementor-spacer\,.e-con>.elementor-widget-spa cer>.elementor-widget-container\,.e-con>.elementor-widget-spacer>.elemento r-widget-container>.elementor-spacer{height:100%}.e-con-inner>.elementor-w idget-spacer>.elementor-widget-container>.elementor-spacer>.elementor-spac er-inner\,.e-con>.elementor-widget-spacer>.elementor-widget-container>.ele mentor-spacer>.elementor-spacer-inner{height:var(--container-widget-height \,var(--spacer-size))}\n\n\nREGISTER HERE\n ATTACH;FMTTYPE=image/jpeg:https://jbcc.co.za/wp-content/uploads/2019/01/se rvices-3-960x600-1.jpeg END:VEVENT BEGIN:VEVENT UID:47@jbcc.co.za DTSTART;TZID=Africa/Johannesburg:20240917T130000 DTEND;TZID=Africa/Johannesburg:20240917T160000 DTSTAMP:20240802T095752Z URL:https://jbcc.co.za/events/extension-of-time-and-role-of-the-principal- agent-webinar-27-august-2024-copy/ SUMMARY:EXTENSION OF TIME AND ROLE OF THE PRINCIPAL AGENT WEBINAR - 17 Sep tember 2024 DESCRIPTION:JBCC MAY 2018 6TH EDITION: CLAUSE 23.0\nGUIDELINES ON HOW TO AD MINISTER EXTENSION OF TIME FOR PRACTICAL COMPLETION\nPresented by – Gera rd Damstra\n\n/*! elementor - v3.10.2 - 29-01-2023 */\n.elementor-widget-d ivider{--divider-border-style:none\;--divider-border-width:1px\;--divider- color:#2c2c2c\;--divider-icon-size:20px\;--divider-element-spacing:10px\;- -divider-pattern-height:24px\;--divider-pattern-size:20px\;--divider-patte rn-url:none\;--divider-pattern-repeat:repeat-x}.elementor-widget-divider . elementor-divider{display:flex}.elementor-widget-divider .elementor-divide r__text{font-size:15px\;line-height:1\;max-width:95%}.elementor-widget-div ider .elementor-divider__element{margin:0 var(--divider-element-spacing)\; flex-shrink:0}.elementor-widget-divider .elementor-icon{font-size:var(--di vider-icon-size)}.elementor-widget-divider .elementor-divider-separator{di splay:flex\;margin:0\;direction:ltr}.elementor-widget-divider--view-line_i con .elementor-divider-separator\,.elementor-widget-divider--view-line_tex t .elementor-divider-separator{align-items:center}.elementor-widget-divide r--view-line_icon .elementor-divider-separator:after\,.elementor-widget-di vider--view-line_icon .elementor-divider-separator:before\,.elementor-widg et-divider--view-line_text .elementor-divider-separator:after\,.elementor- widget-divider--view-line_text .elementor-divider-separator:before{display :block\;content:""\;border-bottom:0\;flex-grow:1\;border-top:var(--divider -border-width) var(--divider-border-style) var(--divider-color)}.elementor -widget-divider--element-align-left .elementor-divider .elementor-divider- separator>\;.elementor-divider__svg:first-of-type{flex-grow:0\;flex-shri nk:100}.elementor-widget-divider--element-align-left .elementor-divider-se parator:before{content:none}.elementor-widget-divider--element-align-left .elementor-divider__element{margin-left:0}.elementor-widget-divider--eleme nt-align-right .elementor-divider .elementor-divider-separator>\;.elemen tor-divider__svg:last-of-type{flex-grow:0\;flex-shrink:100}.elementor-widg et-divider--element-align-right .elementor-divider-separator:after{content :none}.elementor-widget-divider--element-align-right .elementor-divider__e lement{margin-right:0}.elementor-widget-divider:not(.elementor-widget-divi der--view-line_text):not(.elementor-widget-divider--view-line_icon) .eleme ntor-divider-separator{border-top:var(--divider-border-width) var(--divide r-border-style) var(--divider-color)}.elementor-widget-divider--separator- type-pattern{--divider-border-style:none}.elementor-widget-divider--separa tor-type-pattern.elementor-widget-divider--view-line .elementor-divider-se parator\,.elementor-widget-divider--separator-type-pattern:not(.elementor- widget-divider--view-line) .elementor-divider-separator:after\,.elementor- widget-divider--separator-type-pattern:not(.elementor-widget-divider--view -line) .elementor-divider-separator:before\,.elementor-widget-divider--sep arator-type-pattern:not([class*=elementor-widget-divider--view]) .elemento r-divider-separator{width:100%\;min-height:var(--divider-pattern-height)\; -webkit-mask-size:var(--divider-pattern-size) 100%\;mask-size:var(--divide r-pattern-size) 100%\;-webkit-mask-repeat:var(--divider-pattern-repeat)\;m ask-repeat:var(--divider-pattern-repeat)\;background-color:var(--divider-c olor)\;-webkit-mask-image:var(--divider-pattern-url)\;mask-image:var(--div ider-pattern-url)}.elementor-widget-divider--no-spacing{--divider-pattern- size:auto}.elementor-widget-divider--bg-round{--divider-pattern-repeat:rou nd}.rtl .elementor-widget-divider .elementor-divider__text{direction:rtl}. e-con-inner>\;.elementor-widget-divider\,.e-con>\;.elementor-widget-di vider{width:var(--container-widget-width)\;--flex-grow:var(--container-wid get-flex-grow)}\n\nSESSION 1\nJBCC May 2018 6th Edition: Clause 23.0 Guide lines on How to Administer Extension of Time for Practical Completion\n\nP resenter: Gerard Damstra\n\n• Delays where the contractor is not at faul t would normally constitute a valid claim for (EOT).\n• Delays affects c ritical path of projects.\n• Confirming a delay and/ or disruption is no t an easy task: it is a time-consuming process\, especially in multifacete d projects with thousands of activities\, a lot of details\, as well as th e involvement of many stakeholders.\n• It is important for clients\, con tractors\, sub-contractors\, and consultants to understand the fundamental requirements of compiling a successful EOT claim\, and the adjudication o f claims submitted.\n• These training notes will provide those involved in the preparation and adjudication of EOT claims under the JBCC with some essential information to deal more productively with this complex matter. \n• On larger projects\, the magnitude of time-related costs can easily run into millions of rand. With so much at stake\, it is understandable th at delay claims are a major source of disputes in the construction industr y.\n• The proper assessment of delay claims is essential so that the par ties can deal with it without having to resolve the dispute in expensive a nd drawn-out arbitration or litigation processes.\n\nSESSION 2\n\nJBCC MAY 2018 6th Edition: Understanding The Roles of The Various Role Players Inv olved in The Building Contract with Emphasis on The Role of The Principal Agent\n\nPresenter: Gerard Damstra\n\n• The building contract involves a host of role players to establish a successful project - role players all have specific functions to be performed within specific boundaries\, with specific powers entrusted to them.\n• Role players must work together t o ensure a successful project is completed within timeframes and with prof essionalism\, integrity\, honesty and moral standards.\n• Some functions are regulated by contracts between role players\, but others are governed by the standards laid down by society – the so-called boni mores of a c ommunity.\n• Role players must be aware of the impact of their actions.\ n• It is imperative that all parties involved in a project have proper d etailed knowledge of their respective roles\, powers\, duties\, timelines and application of specialised professional contributions to the “team. ”\n• It is the function of the principal agent to bring all the aspect s\, required for a successful building project\, together in a coordinated and orderly manner.\n• The role of the principal agent therefore requir es a proper understanding or else a project may fall apart to the detrimen t of all parties involved.\n• If the role of the principal agent is not fully understood\, chaos may be the result in which all parties suffer fin ancial loss\, impaired reputations and environmental damage.\nVIRTUAL SEMI NAR COST : \nSingle delegate  |  R1 875.00\nMultiple delegates (2 or more)  |  R1 770.00\n\nOne day webinar from 13h00 -16h00\n\nTime shows in Johannesburg\n\nEARN CPD CREDITS!  TOTAL OF 7 HOURS\n(Each session: 3 hours and 1 hour for quiz completion)\n*PLEASE NOTE: Register with the email address that you will use to access the webinar on the day of the s essions.*\n/*! elementor - v3.10.2 - 29-01-2023 */\n.elementor-column .ele mentor-spacer-inner{height:var(--spacer-size)}.e-con{--container-widget-wi dth:100%}.e-con-inner>\;.elementor-widget-spacer\,.e-con>\;.elementor- widget-spacer{width:var(--container-widget-width\,var(--spacer-size))\;--a lign-self:var(--container-widget-align-self\,initial)\;--flex-shrink:0}.e- con-inner>\;.elementor-widget-spacer>\;.elementor-widget-container\,.e -con-inner>\;.elementor-widget-spacer>\;.elementor-widget-container> \;.elementor-spacer\,.e-con>\;.elementor-widget-spacer>\;.elementor-wi dget-container\,.e-con>\;.elementor-widget-spacer>\;.elementor-widget- container>\;.elementor-spacer{height:100%}.e-con-inner>\;.elementor-wi dget-spacer>\;.elementor-widget-container>\;.elementor-spacer>\;.ele mentor-spacer-inner\,.e-con>\;.elementor-widget-spacer>\;.elementor-wi dget-container>\;.elementor-spacer>\;.elementor-spacer-inner{height:va r(--container-widget-height\,var(--spacer-size))}\n\n\nREGISTER HERE\n ATTACH;FMTTYPE=image/jpeg:https://jbcc.co.za/wp-content/uploads/2019/01/se rvices-3-960x600-1.jpeg END:VEVENT BEGIN:VEVENT UID:43@jbcc.co.za DTSTART;TZID=Africa/Johannesburg:20240918T130000 DTEND;TZID=Africa/Johannesburg:20240919T160000 DTSTAMP:20240802T101342Z URL:https://jbcc.co.za/events/nssa-training-18-19-september-2024/ SUMMARY:NSSA TRAINING - 18-19 September 2024 DESCRIPTION:The JBCC is bridging the gap with tailormade training to elevat e subcontractors with skills of administering and understanding JBCC contr acts.NEW NSSA TRAININGOur aim is to provide a clear overview and understan ding of the following topics:• The Law and its application to Constructi on• The importance of Standard Form Contracts\, with a focus on the JBCC • To successfully complete the NSSA Contract Data• To understand Preli minaries• An update on JBCC publications• To have and understanding of the JBCC N/S Subcontract Agreement with a focus on the following clauses: Presenter: Brad BoertjeAn expert in arbitration and adjudication\, having worked on more than 65 cases and affiliated with esteemed organizations li ke CAASA\, the Master Builders Association North\, ASAQS\, Brad has countl ess years of experience in building contacts.  He also sits behind numero us training programs\, having collaborated extensively with IOPSA.Led by a n industry expert\, this seminar guarantees insights and actionable strate gies to your contract administration skills.This is your opportunity to se cure your spot of construction knowledge. DATES : 18 September 2024 : 13 :00 - 16:0019 September 2024 : 13:00 - 16:00Time shows in JohannesburgSin gle delegate : R 1 600.00 incl.Multiple delegates: R1 520.00 incl.This is a virtual\, 2 day course.Click the link below to reserve your spot:REGISTE R HEREDon't miss out on this opportunity ! Join us for a riveting seminar that promises to fuel your success in the construction industry.TERMS & \; CONDITIONS END:VEVENT BEGIN:VEVENT UID:49@jbcc.co.za DTSTART;TZID=Africa/Johannesburg:20240925T130000 DTEND;TZID=Africa/Johannesburg:20240926T160000 DTSTAMP:20240910T143120Z URL:https://jbcc.co.za/events/jbcc-agreements-contracts-2018-2020-25-26-se ptember-2024/ SUMMARY:JBCC AGREEMENTS/CONTRACTS 2018/2020 - 25-26 September 2024 DESCRIPTION:This is a training course conducted online using zoom presented in two sessions starting from 13h00 and ends at 16h00\nPresented by  – Gerard Damstra &\; Brad Boertje\nObjectives:\nThe interpretation and u nderstanding of the JBCC agreements and contracts is fundamental in carryi ng out a successful construction project to final completion stage. Many p rojects stand still due the lack of contract knowledge in implementation. It is crucial that contracting parties adhere and fully understand the JBC C clauses before entering a JBCC agreement. This webinar reviews the JBCC clauses from implementation of a project to the final completion stages an d gives a view to the delegates the challenges that might be experienced i n progamme stages\, remedies that can be used and what to avoid when admin istering a project using the JBCC agreements.\n\n\n\nLearning Outcomes:\n\ n Describe the development of the various types of building contracts in use in South Africa\;\n Identify the important role of the JBCC documents in the South African building industry\;\n Have an in-depth understandin g of the historical background and structure of the JBCC May 2018 6.2nd Ed \;\n Know what the JBCC documents comprise of and its application in the South African building industry and elsewhere in Africa\;\n Know what the duties are of the Principal Agent arising from the JBCC documents\; and\n Understand the mechanisms and day-to-day use of a selection of commonly encountered provisions.\n\n\n\n\nSESSION 1\n\n Construction Law\n Pre-Co ntract Activities\n Risk Management Procurement / Contract Data\n Disput e Resolution\nMediation\nAdjudication\nArbitration\n Definitions\n Offer and Acceptance Documents\n Agents/ Design Duties of the Parties\n Subco ntractors\n\nSESSION 2\n\n Contract Instructions\n Execution &\; Comp letion Penalties (Damages)\n Payments\n Adjustment of the Contract Value \n Insurances &\; Securities\n Suspension &\; Termination\n Diffe rences between editions 4.1\, 6. 1 and 6.2\n State Contract Data\n New C ontracts (SSWC &\; DCC)\n\n\n\n\nWho Can Attend:\n\n Principal Agents and Project Managers\n Architects\n Quantity Surveyors\n Engineers\n B uilding Contractors and Subcontractors\n Employers\n Building Owners\, D evelopers\n Procurement Officers\n Project Financiers\n Legal Advisors\ n\n\n\n\nVIRTUAL SEMINAR COST (FOR BOTH SESSIONS): \nSingle delegate  |   R3 825.00\nMultiple delegates (2 or more)  |  R3 385.00\n\nSession 1: 14 August 2024 01:00 PM   |  Session 2: 15 August 2024 01:00 PM\n\n Time shows in Johannesburg\n\nEARN CPD CREDITS!  TOTAL OF 7 HOURS\n(Eac h session: 3 hours and 1 hour for quiz completion)\n*PLEASE NOTE: Registe r with the email address that you will use to access the webinar on the da y of the sessions.*\n \n\n REGISTER HERE\n ATTACH;FMTTYPE=image/jpeg:https://jbcc.co.za/wp-content/uploads/2019/01/se rvices-3-960x600-1.jpeg END:VEVENT BEGIN:VEVENT UID:50@jbcc.co.za DTSTART;TZID=Africa/Johannesburg:20241016T130000 DTEND;TZID=Africa/Johannesburg:20241017T160000 DTSTAMP:20240805T055442Z URL:https://jbcc.co.za/events/jbcc-agreements-contracts-2018-2020-16-17-oc tober-2024/ SUMMARY:JBCC AGREEMENTS/CONTRACTS 2018/2020 - 16-17 October 2024 DESCRIPTION:This is a training course conducted online using zoom presented in two sessions starting from 13h00 and ends at 16h00\nPresented by  – Gerard Damstra &\; Brad Boertje\nObjectives:\nThe interpretation and u nderstanding of the JBCC agreements and contracts is fundamental in carryi ng out a successful construction project to final completion stage. Many p rojects stand still due the lack of contract knowledge in implementation. It is crucial that contracting parties adhere and fully understand the JBC C clauses before entering a JBCC agreement. This webinar reviews the JBCC clauses from implementation of a project to the final completion stages an d gives a view to the delegates the challenges that might be experienced i n progamme stages\, remedies that can be used and what to avoid when admin istering a project using the JBCC agreements.\n\n\n\nLearning Outcomes:\n\ n Describe the development of the various types of building contracts in use in South Africa\;\n Identify the important role of the JBCC documents in the South African building industry\;\n Have an in-depth understandin g of the historical background and structure of the JBCC May 2018 6.2nd Ed \;\n Know what the JBCC documents comprise of and its application in the South African building industry and elsewhere in Africa\;\n Know what the duties are of the Principal Agent arising from the JBCC documents\; and\n Understand the mechanisms and day-to-day use of a selection of commonly encountered provisions.\n\n\n\n\nSESSION 1\n\n Construction Law\n Pre-Co ntract Activities\n Risk Management Procurement / Contract Data\n Disput e Resolution\nMediation\nAdjudication\nArbitration\n Definitions\n Offer and Acceptance Documents\n Agents/ Design Duties of the Parties\n Subco ntractors\n\nSESSION 2\n\n Contract Instructions\n Execution &\; Comp letion Penalties (Damages)\n Payments\n Adjustment of the Contract Value \n Insurances &\; Securities\n Suspension &\; Termination\n Diffe rences between editions 4.1\, 6. 1 and 6.2\n State Contract Data\n New C ontracts (SSWC &\; DCC)\n\n\n\n\nWho Can Attend:\n\n Principal Agents and Project Managers\n Architects\n Quantity Surveyors\n Engineers\n B uilding Contractors and Subcontractors\n Employers\n Building Owners\, D evelopers\n Procurement Officers\n Project Financiers\n Legal Advisors\ n\n\n\n\nVIRTUAL SEMINAR COST (FOR BOTH SESSIONS): \nSingle delegate  |   R3 825.00\nMultiple delegates (2 or more)  |  R3 385.00\n\nSession 1: 14 August 2024 01:00 PM   |  Session 2: 15 August 2024 01:00 PM\n\n Time shows in Johannesburg\n\nEARN CPD CREDITS!  TOTAL OF 7 HOURS\n(Eac h session: 3 hours and 1 hour for quiz completion)\n*PLEASE NOTE: Registe r with the email address that you will use to access the webinar on the da y of the sessions.*\n \n\n REGISTER HERE\n ATTACH;FMTTYPE=image/jpeg:https://jbcc.co.za/wp-content/uploads/2019/01/se rvices-3-960x600-1.jpeg END:VEVENT BEGIN:VEVENT UID:44@jbcc.co.za DTSTART;TZID=Africa/Johannesburg:20241023T130000 DTEND;TZID=Africa/Johannesburg:20241024T160000 DTSTAMP:20240802T101301Z URL:https://jbcc.co.za/events/nssa-training-23-24-october-2024/ SUMMARY:NSSA TRAINING - 23-24 October 2024 DESCRIPTION:The JBCC is bridging the gap with tailormade training to elevat e subcontractors with skills of administering and understanding JBCC contr acts.NEW NSSA TRAININGOur aim is to provide a clear overview and understan ding of the following topics:• The Law and its application to Constructi on• The importance of Standard Form Contracts\, with a focus on the JBCC • To successfully complete the NSSA Contract Data• To understand Preli minaries• An update on JBCC publications• To have and understanding of the JBCC N/S Subcontract Agreement with a focus on the following clauses: Presenter: Brad BoertjeAn expert in arbitration and adjudication\, having worked on more than 65 cases and affiliated with esteemed organizations li ke CAASA\, the Master Builders Association North\, ASAQS\, Brad has countl ess years of experience in building contacts.  He also sits behind numero us training programs\, having collaborated extensively with IOPSA.Led by a n industry expert\, this seminar guarantees insights and actionable strate gies to your contract administration skills.This is your opportunity to se cure your spot of construction knowledge. DATES : 23 October 2024 : 13:0 0 - 16:0024 October 2024 : 13:00 - 16:00Time shows in JohannesburgSingle delegate : R 1 600.00 incl.Multiple delegates: R1 520.00 incl.This is a vi rtual\, 2 day course.Click the link below to reserve your spot:REGISTER HE REDon't miss out on this opportunity ! Join us for a riveting seminar that promises to fuel your success in the construction industry.TERMS &\; C ONDITIONS END:VEVENT BEGIN:VEVENT UID:46@jbcc.co.za DTSTART;TZID=Africa/Johannesburg:20241024T130000 DTEND;TZID=Africa/Johannesburg:20241024T160000 DTSTAMP:20240802T101606Z URL:https://jbcc.co.za/events/extension-of-time-and-role-of-the-principal- agent-webinar-24-october-2024/ SUMMARY:EXTENSION OF TIME AND ROLE OF THE PRINCIPAL AGENT WEBINAR - 24 Oct ober 2024 DESCRIPTION:JBCC MAY 2018 6TH EDITION: CLAUSE 23.0\nGUIDELINES ON HOW TO AD MINISTER EXTENSION OF TIME FOR PRACTICAL COMPLETION\nPresented by – Gera rd Damstra\n\n/*! elementor - v3.10.2 - 29-01-2023 */\n.elementor-widget-d ivider{--divider-border-style:none\;--divider-border-width:1px\;--divider- color:#2c2c2c\;--divider-icon-size:20px\;--divider-element-spacing:10px\;- -divider-pattern-height:24px\;--divider-pattern-size:20px\;--divider-patte rn-url:none\;--divider-pattern-repeat:repeat-x}.elementor-widget-divider . elementor-divider{display:flex}.elementor-widget-divider .elementor-divide r__text{font-size:15px\;line-height:1\;max-width:95%}.elementor-widget-div ider .elementor-divider__element{margin:0 var(--divider-element-spacing)\; flex-shrink:0}.elementor-widget-divider .elementor-icon{font-size:var(--di vider-icon-size)}.elementor-widget-divider .elementor-divider-separator{di splay:flex\;margin:0\;direction:ltr}.elementor-widget-divider--view-line_i con .elementor-divider-separator\,.elementor-widget-divider--view-line_tex t .elementor-divider-separator{align-items:center}.elementor-widget-divide r--view-line_icon .elementor-divider-separator:after\,.elementor-widget-di vider--view-line_icon .elementor-divider-separator:before\,.elementor-widg et-divider--view-line_text .elementor-divider-separator:after\,.elementor- widget-divider--view-line_text .elementor-divider-separator:before{display :block\;content:""\;border-bottom:0\;flex-grow:1\;border-top:var(--divider -border-width) var(--divider-border-style) var(--divider-color)}.elementor -widget-divider--element-align-left .elementor-divider .elementor-divider- separator>\;.elementor-divider__svg:first-of-type{flex-grow:0\;flex-shri nk:100}.elementor-widget-divider--element-align-left .elementor-divider-se parator:before{content:none}.elementor-widget-divider--element-align-left .elementor-divider__element{margin-left:0}.elementor-widget-divider--eleme nt-align-right .elementor-divider .elementor-divider-separator>\;.elemen tor-divider__svg:last-of-type{flex-grow:0\;flex-shrink:100}.elementor-widg et-divider--element-align-right .elementor-divider-separator:after{content :none}.elementor-widget-divider--element-align-right .elementor-divider__e lement{margin-right:0}.elementor-widget-divider:not(.elementor-widget-divi der--view-line_text):not(.elementor-widget-divider--view-line_icon) .eleme ntor-divider-separator{border-top:var(--divider-border-width) var(--divide r-border-style) var(--divider-color)}.elementor-widget-divider--separator- type-pattern{--divider-border-style:none}.elementor-widget-divider--separa tor-type-pattern.elementor-widget-divider--view-line .elementor-divider-se parator\,.elementor-widget-divider--separator-type-pattern:not(.elementor- widget-divider--view-line) .elementor-divider-separator:after\,.elementor- widget-divider--separator-type-pattern:not(.elementor-widget-divider--view -line) .elementor-divider-separator:before\,.elementor-widget-divider--sep arator-type-pattern:not([class*=elementor-widget-divider--view]) .elemento r-divider-separator{width:100%\;min-height:var(--divider-pattern-height)\; -webkit-mask-size:var(--divider-pattern-size) 100%\;mask-size:var(--divide r-pattern-size) 100%\;-webkit-mask-repeat:var(--divider-pattern-repeat)\;m ask-repeat:var(--divider-pattern-repeat)\;background-color:var(--divider-c olor)\;-webkit-mask-image:var(--divider-pattern-url)\;mask-image:var(--div ider-pattern-url)}.elementor-widget-divider--no-spacing{--divider-pattern- size:auto}.elementor-widget-divider--bg-round{--divider-pattern-repeat:rou nd}.rtl .elementor-widget-divider .elementor-divider__text{direction:rtl}. e-con-inner>\;.elementor-widget-divider\,.e-con>\;.elementor-widget-di vider{width:var(--container-widget-width)\;--flex-grow:var(--container-wid get-flex-grow)}\n\nSESSION 1\nJBCC May 2018 6th Edition: Clause 23.0 Guide lines on How to Administer Extension of Time for Practical Completion\n\nP resenter: Gerard Damstra\n\n• Delays where the contractor is not at faul t would normally constitute a valid claim for (EOT).\n• Delays affects c ritical path of projects.\n• Confirming a delay and/ or disruption is no t an easy task: it is a time-consuming process\, especially in multifacete d projects with thousands of activities\, a lot of details\, as well as th e involvement of many stakeholders.\n• It is important for clients\, con tractors\, sub-contractors\, and consultants to understand the fundamental requirements of compiling a successful EOT claim\, and the adjudication o f claims submitted.\n• These training notes will provide those involved in the preparation and adjudication of EOT claims under the JBCC with some essential information to deal more productively with this complex matter. \n• On larger projects\, the magnitude of time-related costs can easily run into millions of rand. With so much at stake\, it is understandable th at delay claims are a major source of disputes in the construction industr y.\n• The proper assessment of delay claims is essential so that the par ties can deal with it without having to resolve the dispute in expensive a nd drawn-out arbitration or litigation processes.\n\nSESSION 2\n\nJBCC MAY 2018 6th Edition: Understanding The Roles of The Various Role Players Inv olved in The Building Contract with Emphasis on The Role of The Principal Agent\n\nPresenter: Gerard Damstra\n\n• The building contract involves a host of role players to establish a successful project - role players all have specific functions to be performed within specific boundaries\, with specific powers entrusted to them.\n• Role players must work together t o ensure a successful project is completed within timeframes and with prof essionalism\, integrity\, honesty and moral standards.\n• Some functions are regulated by contracts between role players\, but others are governed by the standards laid down by society – the so-called boni mores of a c ommunity.\n• Role players must be aware of the impact of their actions.\ n• It is imperative that all parties involved in a project have proper d etailed knowledge of their respective roles\, powers\, duties\, timelines and application of specialised professional contributions to the “team. ”\n• It is the function of the principal agent to bring all the aspect s\, required for a successful building project\, together in a coordinated and orderly manner.\n• The role of the principal agent therefore requir es a proper understanding or else a project may fall apart to the detrimen t of all parties involved.\n• If the role of the principal agent is not fully understood\, chaos may be the result in which all parties suffer fin ancial loss\, impaired reputations and environmental damage.\nVIRTUAL SEMI NAR COST : \nSingle delegate  |  R1 875.00\nMultiple delegates (2 or more)  |  R1 770.00\n\nOne day webinar from 13h00 -16h00\n\nTime shows in Johannesburg\n\nEARN CPD CREDITS!  TOTAL OF 7 HOURS\n(Each session: 3 hours and 1 hour for quiz completion)\n*PLEASE NOTE: Register with the email address that you will use to access the webinar on the day of the s essions.*\n/*! elementor - v3.10.2 - 29-01-2023 */\n.elementor-column .ele mentor-spacer-inner{height:var(--spacer-size)}.e-con{--container-widget-wi dth:100%}.e-con-inner>\;.elementor-widget-spacer\,.e-con>\;.elementor- widget-spacer{width:var(--container-widget-width\,var(--spacer-size))\;--a lign-self:var(--container-widget-align-self\,initial)\;--flex-shrink:0}.e- con-inner>\;.elementor-widget-spacer>\;.elementor-widget-container\,.e -con-inner>\;.elementor-widget-spacer>\;.elementor-widget-container> \;.elementor-spacer\,.e-con>\;.elementor-widget-spacer>\;.elementor-wi dget-container\,.e-con>\;.elementor-widget-spacer>\;.elementor-widget- container>\;.elementor-spacer{height:100%}.e-con-inner>\;.elementor-wi dget-spacer>\;.elementor-widget-container>\;.elementor-spacer>\;.ele mentor-spacer-inner\,.e-con>\;.elementor-widget-spacer>\;.elementor-wi dget-container>\;.elementor-spacer>\;.elementor-spacer-inner{height:va r(--container-widget-height\,var(--spacer-size))}\n\n\nREGISTER HERE\n ATTACH;FMTTYPE=image/jpeg:https://jbcc.co.za/wp-content/uploads/2019/01/se rvices-3-960x600-1.jpeg END:VEVENT BEGIN:VEVENT UID:45@jbcc.co.za DTSTART;TZID=Africa/Johannesburg:20241112T130000 DTEND;TZID=Africa/Johannesburg:20241113T160000 DTSTAMP:20241101T095227Z URL:https://jbcc.co.za/events/nssa-training-12-13-november-2024/ SUMMARY:NSSA TRAINING - 12-13 November 2024 DESCRIPTION:The JBCC is bridging the gap with tailormade training to elevat e subcontractors with skills of administering and understanding JBCC contr acts.\nNEW NSSA TRAINING\nOur aim is to provide a clear overview and under standing of the following topics:\n\n• The Law and its application to Co nstruction\n• The importance of Standard Form Contracts\, with a focus o n the JBCC\n• To successfully complete the NSSA Contract Data\n• To un derstand Preliminaries\n• An update on JBCC publications\n• To have an d understanding of the JBCC N/S Subcontract Agreement with a focus on the following clauses:\n\nPresenter: Brad Boertje\n\nAn expert in arbitration and adjudication\, having worked on more than 65 cases and affiliated with esteemed organizations like CAASA\, the Master Builders Association North \, ASAQS\, Brad has countless years of experience in building contacts.  He also sits behind numerous training programs\, having collaborated exten sively with IOPSA.\n\nLed by an industry expert\, this seminar guarantees insights and actionable strategies to your contract administration skills. \n\nThis is your opportunity to secure your spot of construction knowledge .\n\nDATES : \n19 November 2024 : 13:00 - 16:00\n20 November 2024 : 13:00 - 16:00\n\nTime shows in Johannesburg\nSingle delegate : R 1 600.00 incl .\nMultiple delegates: R1 520.00 incl.\n\nThis is a virtual\, 2 day course .\nClick the link below to reserve your spot:\nREGISTER HERE\nDon't miss o ut on this opportunity ! Join us for a riveting seminar that promises to f uel your success in the construction industry.\nTERMS &\; CONDITIONS END:VEVENT BEGIN:VEVENT UID:51@jbcc.co.za DTSTART;TZID=Africa/Johannesburg:20241119T130000 DTEND;TZID=Africa/Johannesburg:20241120T160000 DTSTAMP:20241101T100920Z URL:https://jbcc.co.za/events/jbcc-agreements-contracts-2018-2020-19-20-no vember-2024/ SUMMARY:JBCC AGREEMENTS/CONTRACTS 2018/2020 - 19-20 November 2024 DESCRIPTION:This is a training course conducted online using zoom presented in two sessions starting from 13h00 and ends at 16h00Presented by  – G erard Damstra &\; Brad BoertjeObjectives:The interpretation and underst anding of the JBCC agreements and contracts is fundamental in carrying out a successful construction project to final completion stage. Many project s stand still due the lack of contract knowledge in implementation. It is crucial that contracting parties adhere and fully understand the JBCC clau ses before entering a JBCC agreement. This webinar reviews the JBCC clause s from implementation of a project to the final completion stages and give s a view to the delegates the challenges that might be experienced in prog amme stages\, remedies that can be used and what to avoid when administeri ng a project using the JBCC agreements.Learning Outcomes:Describe the deve lopment of the various types of building contracts in use in South Africa\ ;Identify the important role of the JBCC documents in the South African bu ilding industry\;Have an in-depth understanding of the historical backgrou nd and structure of the JBCC May 2018 6.2nd Ed\;Know what the JBCC documen ts comprise of and its application in the South African building industry and elsewhere in Africa\;Know what the duties are of the Principal Agent a rising from the JBCC documents\; andUnderstand the mechanisms and day-to-d ay use of a selection of commonly encountered provisions.SESSION 1Construc tion LawPre-Contract ActivitiesRisk Management Procurement / Contract Data Dispute ResolutionMediationAdjudicationArbitrationDefinitionsOffer and Acc eptance DocumentsAgents/ Design Duties of the PartiesSubcontractorsSESSION 2Contract InstructionsExecution &\; Completion Penalties (Damages)Paym entsAdjustment of the Contract ValueInsurances &\; SecuritiesSuspension &\; TerminationDifferences between editions 4.1\, 6. 1 and 6.2State Co ntract DataNew Contracts (SSWC &\; DCC)Who Can Attend:Principal Agents and Project ManagersArchitectsQuantity SurveyorsEngineersBuilding Contract ors and SubcontractorsEmployersBuilding Owners\, DevelopersProcurement Off icersProject FinanciersLegal AdvisorsVIRTUAL SEMINAR COST (FOR BOTH SESSIO NS): Single delegate  |  R3 825.00Multiple delegates (2 or more)  |   R3 385.00Session 1: 19 November2024 01:00 PM   |  Session 2: 20 Nov ember 2024 01:00 PMTime shows in JohannesburgEARN CPD CREDITS!  TOTAL O F 7 HOURS(Each session: 3 hours and 1 hour for quiz completion)*PLEASE NOT E: Register with the email address that you will use to access the webina r on the day of the sessions.* REGISTER HERE ATTACH;FMTTYPE=image/jpeg:https://jbcc.co.za/wp-content/uploads/2019/01/se rvices-3-960x600-1.jpeg END:VEVENT BEGIN:VEVENT UID:48@jbcc.co.za DTSTART;TZID=Africa/Johannesburg:20241121T130000 DTEND;TZID=Africa/Johannesburg:20241121T160000 DTSTAMP:20241205T084649Z URL:https://jbcc.co.za/events/extension-of-time-and-role-of-the-principal- agent-webinar-21-november-2024/ SUMMARY:EXTENSION OF TIME AND ROLE OF THE PRINCIPAL AGENT WEBINAR - 21 Nov ember 2024 DESCRIPTION:JBCC MAY 2018 6TH EDITION: CLAUSE 23.0GUIDELINES ON HOW TO ADMI NISTER EXTENSION OF TIME FOR PRACTICAL COMPLETIONPresented by – Gerard D amstra/*! elementor - v3.10.2 - 29-01-2023 */.elementor-widget-divider{--d ivider-border-style:none\;--divider-border-width:1px\;--divider-color:#2c2 c2c\;--divider-icon-size:20px\;--divider-element-spacing:10px\;--divider-p attern-height:24px\;--divider-pattern-size:20px\;--divider-pattern-url:non e\;--divider-pattern-repeat:repeat-x}.elementor-widget-divider .elementor- divider{display:flex}.elementor-widget-divider .elementor-divider__text{fo nt-size:15px\;line-height:1\;max-width:95%}.elementor-widget-divider .elem entor-divider__element{margin:0 var(--divider-element-spacing)\;flex-shrin k:0}.elementor-widget-divider .elementor-icon{font-size:var(--divider-icon -size)}.elementor-widget-divider .elementor-divider-separator{display:flex \;margin:0\;direction:ltr}.elementor-widget-divider--view-line_icon .eleme ntor-divider-separator\,.elementor-widget-divider--view-line_text .element or-divider-separator{align-items:center}.elementor-widget-divider--view-li ne_icon .elementor-divider-separator:after\,.elementor-widget-divider--vie w-line_icon .elementor-divider-separator:before\,.elementor-widget-divider --view-line_text .elementor-divider-separator:after\,.elementor-widget-div ider--view-line_text .elementor-divider-separator:before{display:block\;co ntent:""\;border-bottom:0\;flex-grow:1\;border-top:var(--divider-border-wi dth) var(--divider-border-style) var(--divider-color)}.elementor-widget-di vider--element-align-left .elementor-divider .elementor-divider-separator> .elementor-divider__svg:first-of-type{flex-grow:0\;flex-shrink:100}.elemen tor-widget-divider--element-align-left .elementor-divider-separator:before {content:none}.elementor-widget-divider--element-align-left .elementor-div ider__element{margin-left:0}.elementor-widget-divider--element-align-right .elementor-divider .elementor-divider-separator>.elementor-divider__svg:l ast-of-type{flex-grow:0\;flex-shrink:100}.elementor-widget-divider--elemen t-align-right .elementor-divider-separator:after{content:none}.elementor-w idget-divider--element-align-right .elementor-divider__element{margin-righ t:0}.elementor-widget-divider:not(.elementor-widget-divider--view-line_tex t):not(.elementor-widget-divider--view-line_icon) .elementor-divider-separ ator{border-top:var(--divider-border-width) var(--divider-border-style) va r(--divider-color)}.elementor-widget-divider--separator-type-pattern{--div ider-border-style:none}.elementor-widget-divider--separator-type-pattern.e lementor-widget-divider--view-line .elementor-divider-separator\,.elemento r-widget-divider--separator-type-pattern:not(.elementor-widget-divider--vi ew-line) .elementor-divider-separator:after\,.elementor-widget-divider--se parator-type-pattern:not(.elementor-widget-divider--view-line) .elementor- divider-separator:before\,.elementor-widget-divider--separator-type-patter n:not([class*=elementor-widget-divider--view]) .elementor-divider-separato r{width:100%\;min-height:var(--divider-pattern-height)\;-webkit-mask-size: var(--divider-pattern-size) 100%\;mask-size:var(--divider-pattern-size) 10 0%\;-webkit-mask-repeat:var(--divider-pattern-repeat)\;mask-repeat:var(--d ivider-pattern-repeat)\;background-color:var(--divider-color)\;-webkit-mas k-image:var(--divider-pattern-url)\;mask-image:var(--divider-pattern-url)} .elementor-widget-divider--no-spacing{--divider-pattern-size:auto}.element or-widget-divider--bg-round{--divider-pattern-repeat:round}.rtl .elementor -widget-divider .elementor-divider__text{direction:rtl}.e-con-inner>.eleme ntor-widget-divider\,.e-con>.elementor-widget-divider{width:var(--containe r-widget-width)\;--flex-grow:var(--container-widget-flex-grow)}SESSION 1JB CC May 2018 6th Edition: Clause 23.0 Guidelines on How to Administer Exten sion of Time for Practical CompletionPresenter: Gerard Damstra• Delays w here the contractor is not at fault would normally constitute a valid clai m for (EOT).• Delays affects critical path of projects.• Confirming a delay and/ or disruption is not an easy task: it is a time-consuming proce ss\, especially in multifaceted projects with thousands of activities\, a lot of details\, as well as the involvement of many stakeholders.• It is important for clients\, contractors\, sub-contractors\, and consultants t o understand the fundamental requirements of compiling a successful EOT cl aim\, and the adjudication of claims submitted.• These training notes wi ll provide those involved in the preparation and adjudication of EOT claim s under the JBCC with some essential information to deal more productively with this complex matter.• On larger projects\, the magnitude of time-r elated costs can easily run into millions of rand. With so much at stake\, it is understandable that delay claims are a major source of disputes in the construction industry.• The proper assessment of delay claims is ess ential so that the parties can deal with it without having to resolve the dispute in expensive and drawn-out arbitration or litigation processes.SES SION 2JBCC MAY 2018 6th Edition: Understanding The Roles of The Various Ro le Players Involved in The Building Contract with Emphasis on The Role of The Principal AgentPresenter: Gerard Damstra• The building contract invo lves a host of role players to establish a successful project - role playe rs all have specific functions to be performed within specific boundaries\ , with specific powers entrusted to them.• Role players must work togeth er to ensure a successful project is completed within timeframes and with professionalism\, integrity\, honesty and moral standards.• Some functio ns are regulated by contracts between role players\, but others are govern ed by the standards laid down by society – the so-called boni mores of a community.• Role players must be aware of the impact of their actions. • It is imperative that all parties involved in a project have proper de tailed knowledge of their respective roles\, powers\, duties\, timelines a nd application of specialised professional contributions to the “team. ”• It is the function of the principal agent to bring all the aspects\ , required for a successful building project\, together in a coordinated a nd orderly manner.• The role of the principal agent therefore requires a proper understanding or else a project may fall apart to the detriment of all parties involved.• If the role of the principal agent is not fully understood\, chaos may be the result in which all parties suffer financial loss\, impaired reputations and environmental damage.VIRTUAL SEMINAR COST : Single delegate  |  R1 875.00Multiple delegates (2 or more)  |   R1 770.00One day webinar from 13h00 -16h00Time shows in JohannesburgEAR N CPD CREDITS!  TOTAL OF 7 HOURS(Each session: 3 hours and 1 hour for qu iz completion)*PLEASE NOTE: Register with the email address that you will use to access the webinar on the day of the sessions.*/*! elementor - v3. 10.2 - 29-01-2023 */.elementor-column .elementor-spacer-inner{height:var(- -spacer-size)}.e-con{--container-widget-width:100%}.e-con-inner>.elementor -widget-spacer\,.e-con>.elementor-widget-spacer{width:var(--container-widg et-width\,var(--spacer-size))\;--align-self:var(--container-widget-align-s elf\,initial)\;--flex-shrink:0}.e-con-inner>.elementor-widget-spacer>.elem entor-widget-container\,.e-con-inner>.elementor-widget-spacer>.elementor-w idget-container>.elementor-spacer\,.e-con>.elementor-widget-spacer>.elemen tor-widget-container\,.e-con>.elementor-widget-spacer>.elementor-widget-co ntainer>.elementor-spacer{height:100%}.e-con-inner>.elementor-widget-space r>.elementor-widget-container>.elementor-spacer>.elementor-spacer-inner\,. e-con>.elementor-widget-spacer>.elementor-widget-container>.elementor-spac er>.elementor-spacer-inner{height:var(--container-widget-height\,var(--spa cer-size))}REGISTER HERE ATTACH;FMTTYPE=image/jpeg:https://jbcc.co.za/wp-content/uploads/2019/01/se rvices-3-960x600-1.jpeg END:VEVENT BEGIN:VEVENT UID:53@jbcc.co.za DTSTART;TZID=Africa/Johannesburg:20250218T130000 DTEND;TZID=Africa/Johannesburg:20250219T160000 DTSTAMP:20250121T110135Z URL:https://jbcc.co.za/events/nssa-training-18-19-february-2025/ SUMMARY:NSSA TRAINING - 18-19 February 2025 DESCRIPTION:The JBCC is bridging the gap with tailormade training to elevat e subcontractors with skills of administering and understanding JBCC contr acts.NEW NSSA TRAININGOur aim is to provide a clear overview and understan ding of the following topics:• The Law and its application to Constructi on• The importance of Standard Form Contracts\, with a focus on the JBCC • To successfully complete the NSSA Contract Data• To understand Preli minaries• An update on JBCC publications• To have and understanding of the JBCC N/S Subcontract Agreement with a focus on the following clauses: An expert in arbitration and adjudication\, having worked on more than 65 cases and affiliated with esteemed organizations like CAASA\, the Master B uilders Association North\, ASAQS\, Brad has countless years of experience in building contacts.  He also sits behind numerous training programs\, having collaborated extensively with IOPSA.Led by an industry expert\, thi s seminar guarantees insights and actionable strategies to your contract a dministration skills.This is your opportunity to secure your spot of const ruction knowledge. DATES : 18 February 2025 : 13:00 - 16:0019 February 2 025 : 13:00 - 16:00Time shows in JohannesburgSingle delegate : R 1 600.00 incl.Multiple delegates: R1 520.00 incl.This is a virtual\, 2 day course. Click the link below to reserve your spot:REGISTER HEREDon't miss out on t his opportunity ! Join us for a riveting seminar that promises to fuel you r success in the construction industry.TERMS &\; CONDITIONS END:VEVENT BEGIN:VEVENT UID:52@jbcc.co.za DTSTART;TZID=Africa/Johannesburg:20250227T130000 DTEND;TZID=Africa/Johannesburg:20250227T160000 DTSTAMP:20250109T092029Z URL:https://jbcc.co.za/events/extension-of-time-and-role-of-the-principal- agent-webinar-27-february-2025/ SUMMARY:EXTENSION OF TIME AND ROLE OF THE PRINCIPAL AGENT WEBINAR - 27 Feb ruary 2025 DESCRIPTION:JBCC MAY 2018 6TH EDITION: CLAUSE 23.0\nGUIDELINES ON HOW TO AD MINISTER EXTENSION OF TIME FOR PRACTICAL COMPLETION\nSESSION 1\nJBCC May 2 018 6th Edition: Clause 23.0 Guidelines on How to Administer Extension of Time for Practical Completion\n\n• Delays where the contractor is not at fault would normally constitute a valid claim for (EOT).\n• Delays affe cts critical path of projects.\n• Confirming a delay and/ or disruption is not an easy task: it is a time-consuming process\, especially in multif aceted projects with thousands of activities\, a lot of details\, as well as the involvement of many stakeholders.\n• It is important for clients\ , contractors\, sub-contractors\, and consultants to understand the fundam ental requirements of compiling a successful EOT claim\, and the adjudicat ion of claims submitted.\n• These training notes will provide those invo lved in the preparation and adjudication of EOT claims under the JBCC with some essential information to deal more productively with this complex ma tter.\n• On larger projects\, the magnitude of time-related costs can ea sily run into millions of rand. With so much at stake\, it is understandab le that delay claims are a major source of disputes in the construction in dustry.\n• The proper assessment of delay claims is essential so that th e parties can deal with it without having to resolve the dispute in expens ive and drawn-out arbitration or litigation processes.\n\nSESSION 2\n\nJBC C MAY 2018 6th Edition: Understanding The Roles of The Various Role Player s Involved in The Building Contract with Emphasis on The Role of The Princ ipal Agent\n\n• The building contract involves a host of role players to establish a successful project - role players all have specific functions to be performed within specific boundaries\, with specific powers entrust ed to them.\n• Role players must work together to ensure a successful pr oject is completed within timeframes and with professionalism\, integrity\ , honesty and moral standards.\n• Some functions are regulated by contra cts between role players\, but others are governed by the standards laid d own by society – the so-called boni mores of a community.\n• Role play ers must be aware of the impact of their actions.\n• It is imperative th at all parties involved in a project have proper detailed knowledge of the ir respective roles\, powers\, duties\, timelines and application of speci alised professional contributions to the “team.”\n• It is the functi on of the principal agent to bring all the aspects\, required for a succes sful building project\, together in a coordinated and orderly manner.\n• The role of the principal agent therefore requires a proper understanding or else a project may fall apart to the detriment of all parties involved .\n• If the role of the principal agent is not fully understood\, chaos may be the result in which all parties suffer financial loss\, impaired re putations and environmental damage.\nVIRTUAL SEMINAR COST : \nSingle dele gate  |  R1 875.00\nMultiple delegates (2 or more)  |  R1 770.00\n \nOne day webinar from 13h00 -16h00\n\nTime shows in Johannesburg\n\nEARN CPD CREDITS!  TOTAL OF 7 HOURS\n(Each session: 3 hours and 1 hour for q uiz completion)\n*PLEASE NOTE: Register with the email address that you w ill use to access the webinar on the day of the sessions.*\n\nREGISTER HER E\n\n ATTACH;FMTTYPE=image/jpeg:https://jbcc.co.za/wp-content/uploads/2019/01/se rvices-3-960x600-1.jpeg END:VEVENT BEGIN:VEVENT UID:64@jbcc.co.za DTSTART;TZID=Africa/Johannesburg:20250312T130000 DTEND;TZID=Africa/Johannesburg:20250313T160000 DTSTAMP:20250109T090015Z URL:https://jbcc.co.za/events/jbcc-agreements-contracts-2018-2020-12-13-ma rch-2025/ SUMMARY:JBCC AGREEMENTS/CONTRACTS 2018/2020 - 12-13 March 2025 DESCRIPTION:This is a training course conducted online using zoom presented in two sessions starting from 13h00 and ends at 16h00Presented by  – G erard Damstra &\; Brad BoertjeObjectives:The interpretation and underst anding of the JBCC agreements and contracts is fundamental in carrying out a successful construction project to final completion stage. Many project s stand still due the lack of contract knowledge in implementation. It is crucial that contracting parties adhere and fully understand the JBCC clau ses before entering a JBCC agreement. This webinar reviews the JBCC clause s from implementation of a project to the final completion stages and give s a view to the delegates the challenges that might be experienced in prog amme stages\, remedies that can be used and what to avoid when administeri ng a project using the JBCC agreements.Learning Outcomes:Describe the deve lopment of the various types of building contracts in use in South Africa\ ;Identify the important role of the JBCC documents in the South African bu ilding industry\;Have an in-depth understanding of the historical backgrou nd and structure of the JBCC May 2018 6.2nd Ed\;Know what the JBCC documen ts comprise of and its application in the South African building industry and elsewhere in Africa\;Know what the duties are of the Principal Agent a rising from the JBCC documents\; andUnderstand the mechanisms and day-to-d ay use of a selection of commonly encountered provisions.SESSION 1Construc tion LawPre-Contract ActivitiesRisk Management Procurement / Contract Data Dispute ResolutionMediationAdjudicationArbitrationDefinitionsOffer and Acc eptance DocumentsAgents/ Design Duties of the PartiesSubcontractorsSESSION 2Contract InstructionsExecution &\; Completion Penalties (Damages)Paym entsAdjustment of the Contract ValueInsurances &\; SecuritiesSuspension &\; TerminationDifferences between editions 4.1\, 6. 1 and 6.2State Co ntract DataNew Contracts (SSWC &\; DCC)Who Can Attend:Principal Agents and Project ManagersArchitectsQuantity SurveyorsEngineersBuilding Contract ors and SubcontractorsEmployersBuilding Owners\, DevelopersProcurement Off icersProject FinanciersLegal AdvisorsVIRTUAL SEMINAR COST (FOR BOTH SESSIO NS): Single delegate  |  R3 825.00Multiple delegates (2 or more)  |   R3 385.00Session 1: 12 March 2025 01:00 PM   |  Session 2: 13 March 2025 01:00 PMTime shows in JohannesburgEARN CPD CREDITS!  TOTAL OF 7 H OURS(Each session: 3 hours and 1 hour for quiz completion)*PLEASE NOTE: R egister with the email address that you will use to access the webinar on the day of the sessions.* REGISTER HERE ATTACH;FMTTYPE=image/jpeg:https://jbcc.co.za/wp-content/uploads/2019/01/se rvices-3-960x600-1.jpeg END:VEVENT BEGIN:VEVENT UID:58@jbcc.co.za DTSTART;TZID=Africa/Johannesburg:20250327T130000 DTEND;TZID=Africa/Johannesburg:20250328T160000 DTSTAMP:20250109T091552Z URL:https://jbcc.co.za/events/nssa-training-27-28-march-2025/ SUMMARY:NSSA TRAINING - 27-28 March 2025 DESCRIPTION:The JBCC is bridging the gap with tailormade training to elevat e subcontractors with skills of administering and understanding JBCC contr acts.\nNEW NSSA TRAINING\nOur aim is to provide a clear overview and under standing of the following topics:\n\n• The Law and its application to Co nstruction\n• The importance of Standard Form Contracts\, with a focus o n the JBCC\n• To successfully complete the NSSA Contract Data\n• To un derstand Preliminaries\n• An update on JBCC publications\n• To have an d understanding of the JBCC N/S Subcontract Agreement with a focus on the following clauses:\n\nAn expert in arbitration and adjudication\, having w orked on more than 65 cases and affiliated with esteemed organizations lik e CAASA\, the Master Builders Association North\, ASAQS\, Brad has countle ss years of experience in building contacts.  He also sits behind numerou s training programs\, having collaborated extensively with IOPSA.\n\nLed b y an industry expert\, this seminar guarantees insights and actionable str ategies to your contract administration skills.\n\nThis is your opportunit y to secure your spot of construction knowledge.\n\nDATES : \n27 March 20 25 : 13:00 - 16:00\n28 March 2025 : 13:00 - 16:00\n\nTime shows in Johann esburg\nSingle delegate : R 1 600.00 incl.\nMultiple delegates: R1 520.00 incl.\n\nThis is a virtual\, 2 day course.\nClick the link below to reserv e your spot:\nREGISTER HERE\nDon't miss out on this opportunity ! Join us for a riveting seminar that promises to fuel your success in the construct ion industry.\nTERMS &\; CONDITIONS END:VEVENT BEGIN:VEVENT UID:54@jbcc.co.za DTSTART;TZID=Africa/Johannesburg:20250410T130000 DTEND;TZID=Africa/Johannesburg:20250410T160000 DTSTAMP:20250109T082740Z URL:https://jbcc.co.za/events/extension-of-time-and-role-of-the-principal- agent-webinar-10-april-2025/ SUMMARY:EXTENSION OF TIME AND ROLE OF THE PRINCIPAL AGENT WEBINAR - 10 Apr il 2025 DESCRIPTION:JBCC MAY 2018 6TH EDITION: CLAUSE 23.0GUIDELINES ON HOW TO ADMI NISTER EXTENSION OF TIME FOR PRACTICAL COMPLETIONSESSION 1JBCC May 2018 6t h Edition: Clause 23.0 Guidelines on How to Administer Extension of Time f or Practical Completion • Delays where the contractor is not at fault w ould normally constitute a valid claim for (EOT).• Delays affects critic al path of projects.• Confirming a delay and/ or disruption is not an ea sy task: it is a time-consuming process\, especially in multifaceted proje cts with thousands of activities\, a lot of details\, as well as the invol vement of many stakeholders.• It is important for clients\, contractors\ , sub-contractors\, and consultants to understand the fundamental requirem ents of compiling a successful EOT claim\, and the adjudication of claims submitted.• These training notes will provide those involved in the prep aration and adjudication of EOT claims under the JBCC with some essential information to deal more productively with this complex matter.• On larg er projects\, the magnitude of time-related costs can easily run into mill ions of rand. With so much at stake\, it is understandable that delay clai ms are a major source of disputes in the construction industry.• The pro per assessment of delay claims is essential so that the parties can deal w ith it without having to resolve the dispute in expensive and drawn-out ar bitration or litigation processes.SESSION 2JBCC MAY 2018 6th Edition: Unde rstanding The Roles of The Various Role Players Involved in The Building C ontract with Emphasis on The Role of The Principal Agent • The building contract involves a host of role players to establish a successful projec t - role players all have specific functions to be performed within specif ic boundaries\, with specific powers entrusted to them.• Role players mu st work together to ensure a successful project is completed within timefr ames and with professionalism\, integrity\, honesty and moral standards. • Some functions are regulated by contracts between role players\, but o thers are governed by the standards laid down by society – the so-called boni mores of a community.• Role players must be aware of the impact of their actions.• It is imperative that all parties involved in a project have proper detailed knowledge of their respective roles\, powers\, dutie s\, timelines and application of specialised professional contributions to the “team.”• It is the function of the principal agent to bring all the aspects\, required for a successful building project\, together in a coordinated and orderly manner.• The role of the principal agent therefo re requires a proper understanding or else a project may fall apart to the detriment of all parties involved.• If the role of the principal agent is not fully understood\, chaos may be the result in which all parties suf fer financial loss\, impaired reputations and environmental damage.VIRTUAL SEMINAR COST : Single delegate  |  R1 875.00Multiple delegates (2 or more)  |  R1 770.00One day webinar from 13h00 -16h00Time shows in Jo hannesburgEARN CPD CREDITS!  TOTAL OF 7 HOURS(Each session: 3 hours and 1 hour for quiz completion)*PLEASE NOTE: Register with the email address that you will use to access the webinar on the day of the sessions.*REGIST ER HERE  ATTACH;FMTTYPE=image/jpeg:https://jbcc.co.za/wp-content/uploads/2019/01/se rvices-3-960x600-1.jpeg END:VEVENT BEGIN:VEVENT UID:65@jbcc.co.za DTSTART;TZID=Africa/Johannesburg:20250514T130000 DTEND;TZID=Africa/Johannesburg:20250515T160000 DTSTAMP:20250109T090549Z URL:https://jbcc.co.za/events/jbcc-agreements-contracts-2018-2020-14-15-ma y-2025/ SUMMARY:JBCC AGREEMENTS/CONTRACTS 2018/2020 - 14-15 May 2025 DESCRIPTION:This is a training course conducted online using zoom presented in two sessions starting from 13h00 and ends at 16h00Presented by  – G erard Damstra &\; Brad BoertjeObjectives:The interpretation and underst anding of the JBCC agreements and contracts is fundamental in carrying out a successful construction project to final completion stage. Many project s stand still due the lack of contract knowledge in implementation. It is crucial that contracting parties adhere and fully understand the JBCC clau ses before entering a JBCC agreement. This webinar reviews the JBCC clause s from implementation of a project to the final completion stages and give s a view to the delegates the challenges that might be experienced in prog amme stages\, remedies that can be used and what to avoid when administeri ng a project using the JBCC agreements.Learning Outcomes:Describe the deve lopment of the various types of building contracts in use in South Africa\ ;Identify the important role of the JBCC documents in the South African bu ilding industry\;Have an in-depth understanding of the historical backgrou nd and structure of the JBCC May 2018 6.2nd Ed\;Know what the JBCC documen ts comprise of and its application in the South African building industry and elsewhere in Africa\;Know what the duties are of the Principal Agent a rising from the JBCC documents\; andUnderstand the mechanisms and day-to-d ay use of a selection of commonly encountered provisions.SESSION 1Construc tion LawPre-Contract ActivitiesRisk Management Procurement / Contract Data Dispute ResolutionMediationAdjudicationArbitrationDefinitionsOffer and Acc eptance DocumentsAgents/ Design Duties of the PartiesSubcontractorsSESSION 2Contract InstructionsExecution &\; Completion Penalties (Damages)Paym entsAdjustment of the Contract ValueInsurances &\; SecuritiesSuspension &\; TerminationDifferences between editions 4.1\, 6. 1 and 6.2State Co ntract DataNew Contracts (SSWC &\; DCC)Who Can Attend:Principal Agents and Project ManagersArchitectsQuantity SurveyorsEngineersBuilding Contract ors and SubcontractorsEmployersBuilding Owners\, DevelopersProcurement Off icersProject FinanciersLegal AdvisorsVIRTUAL SEMINAR COST (FOR BOTH SESSIO NS): Single delegate  |  R3 825.00Multiple delegates (2 or more)  |   R3 385.00Session 1: 14 May 2025 01:00 PM   |  Session 2: 15 May 202 5 01:00 PMTime shows in JohannesburgEARN CPD CREDITS!  TOTAL OF 7 HOURS (Each session: 3 hours and 1 hour for quiz completion)*PLEASE NOTE: Regis ter with the email address that you will use to access the webinar on the day of the sessions.* REGISTER HERE ATTACH;FMTTYPE=image/jpeg:https://jbcc.co.za/wp-content/uploads/2019/01/se rvices-3-960x600-1.jpeg END:VEVENT BEGIN:VEVENT UID:59@jbcc.co.za DTSTART;TZID=Africa/Johannesburg:20250520T130000 DTEND;TZID=Africa/Johannesburg:20250521T160000 DTSTAMP:20250109T091648Z URL:https://jbcc.co.za/events/nssa-training-20-21-may-2025-copy/ SUMMARY:NSSA TRAINING - 20-21 May 2025 DESCRIPTION:The JBCC is bridging the gap with tailormade training to elevat e subcontractors with skills of administering and understanding JBCC contr acts.\nNEW NSSA TRAINING\nOur aim is to provide a clear overview and under standing of the following topics:\n\n• The Law and its application to Co nstruction\n• The importance of Standard Form Contracts\, with a focus o n the JBCC\n• To successfully complete the NSSA Contract Data\n• To un derstand Preliminaries\n• An update on JBCC publications\n• To have an d understanding of the JBCC N/S Subcontract Agreement with a focus on the following clauses:\n\nAn expert in arbitration and adjudication\, having w orked on more than 65 cases and affiliated with esteemed organizations lik e CAASA\, the Master Builders Association North\, ASAQS\, Brad has countle ss years of experience in building contacts.  He also sits behind numerou s training programs\, having collaborated extensively with IOPSA.\n\nLed b y an industry expert\, this seminar guarantees insights and actionable str ategies to your contract administration skills.\n\nThis is your opportunit y to secure your spot of construction knowledge.\n\nDATES : \n20 May 2025 : 13:00 - 16:00\n21 May 2025 : 13:00 - 16:00\n\nTime shows in Johannesbu rg\nSingle delegate : R 1 600.00 incl.\nMultiple delegates: R1 520.00 incl .\n\nThis is a virtual\, 2 day course.\nClick the link below to reserve yo ur spot:\nREGISTER HERE\nDon't miss out on this opportunity ! Join us for a riveting seminar that promises to fuel your success in the construction industry.\nTERMS &\; CONDITIONS END:VEVENT BEGIN:VEVENT UID:55@jbcc.co.za DTSTART;TZID=Africa/Johannesburg:20250611T130000 DTEND;TZID=Africa/Johannesburg:20250611T160000 DTSTAMP:20250605T060023Z URL:https://jbcc.co.za/events/extension-of-time-and-role-of-the-principal- agent-webinar-11-june-2025/ SUMMARY:EXTENSION OF TIME AND ROLE OF THE PRINCIPAL AGENT WEBINAR - 11 Jun e 2025 DESCRIPTION:JBCC MAY 2018 6TH EDITION: CLAUSE 23.0GUIDELINES ON HOW TO ADMI NISTER EXTENSION OF TIME FOR PRACTICAL COMPLETIONSESSION 1JBCC May 2018 6t h Edition: Clause 23.0 Guidelines on How to Administer Extension of Time f or Practical Completion• Delays where the contractor is not at fault wou ld normally constitute a valid claim for (EOT).• Delays affects critical path of projects.• Confirming a delay and/ or disruption is not an easy task: it is a time-consuming process\, especially in multifaceted project s with thousands of activities\, a lot of details\, as well as the involve ment of many stakeholders.• It is important for clients\, contractors\, sub-contractors\, and consultants to understand the fundamental requiremen ts of compiling a successful EOT claim\, and the adjudication of claims su bmitted.• These training notes will provide those involved in the prepar ation and adjudication of EOT claims under the JBCC with some essential in formation to deal more productively with this complex matter.• On larger projects\, the magnitude of time-related costs can easily run into millio ns of rand. With so much at stake\, it is understandable that delay claims are a major source of disputes in the construction industry.• The prope r assessment of delay claims is essential so that the parties can deal wit h it without having to resolve the dispute in expensive and drawn-out arbi tration or litigation processes.SESSION 2JBCC MAY 2018 6th Edition: Unders tanding The Roles of The Various Role Players Involved in The Building Con tract with Emphasis on The Role of The Principal Agent• The building con tract involves a host of role players to establish a successful project - role players all have specific functions to be performed within specific b oundaries\, with specific powers entrusted to them.• Role players must w ork together to ensure a successful project is completed within timeframes and with professionalism\, integrity\, honesty and moral standards.• So me functions are regulated by contracts between role players\, but others are governed by the standards laid down by society – the so-called boni mores of a community.• Role players must be aware of the impact of their actions.• It is imperative that all parties involved in a project have proper detailed knowledge of their respective roles\, powers\, duties\, ti melines and application of specialised professional contributions to the “team.”• It is the function of the principal agent to bring all the aspects\, required for a successful building project\, together in a coord inated and orderly manner.• The role of the principal agent therefore re quires a proper understanding or else a project may fall apart to the detr iment of all parties involved.• If the role of the principal agent is no t fully understood\, chaos may be the result in which all parties suffer f inancial loss\, impaired reputations and environmental damage.VIRTUAL SEMI NAR COST : Single delegate  |  R1 875.00Multiple delegates (2 or more )  |  R1 770.00One day webinar from 13h00 -16h00Time shows in Johanne sburg Earn CPD Credits! Total of 4 hoursWebinar session: 3 hours and 1 ho ur for quiz completion*PLEASE NOTE: Register with the email address that you will use to access the webinar on the day of the sessions.*REGISTER HE RE  ATTACH;FMTTYPE=image/jpeg:https://jbcc.co.za/wp-content/uploads/2019/01/se rvices-3-960x600-1.jpeg END:VEVENT BEGIN:VEVENT UID:66@jbcc.co.za DTSTART;TZID=Africa/Johannesburg:20250715T130000 DTEND;TZID=Africa/Johannesburg:20250716T160000 DTSTAMP:20250109T090804Z URL:https://jbcc.co.za/events/jbcc-agreements-contracts-2018-2020-15-16-ju ly-2025/ SUMMARY:JBCC AGREEMENTS/CONTRACTS 2018/2020 - 15-16 July 2025 DESCRIPTION:This is a training course conducted online using zoom presented in two sessions starting from 13h00 and ends at 16h00Presented by  – G erard Damstra &\; Brad BoertjeObjectives:The interpretation and underst anding of the JBCC agreements and contracts is fundamental in carrying out a successful construction project to final completion stage. Many project s stand still due the lack of contract knowledge in implementation. It is crucial that contracting parties adhere and fully understand the JBCC clau ses before entering a JBCC agreement. This webinar reviews the JBCC clause s from implementation of a project to the final completion stages and give s a view to the delegates the challenges that might be experienced in prog amme stages\, remedies that can be used and what to avoid when administeri ng a project using the JBCC agreements.Learning Outcomes:Describe the deve lopment of the various types of building contracts in use in South Africa\ ;Identify the important role of the JBCC documents in the South African bu ilding industry\;Have an in-depth understanding of the historical backgrou nd and structure of the JBCC May 2018 6.2nd Ed\;Know what the JBCC documen ts comprise of and its application in the South African building industry and elsewhere in Africa\;Know what the duties are of the Principal Agent a rising from the JBCC documents\; andUnderstand the mechanisms and day-to-d ay use of a selection of commonly encountered provisions.SESSION 1Construc tion LawPre-Contract ActivitiesRisk Management Procurement / Contract Data Dispute ResolutionMediationAdjudicationArbitrationDefinitionsOffer and Acc eptance DocumentsAgents/ Design Duties of the PartiesSubcontractorsSESSION 2Contract InstructionsExecution &\; Completion Penalties (Damages)Paym entsAdjustment of the Contract ValueInsurances &\; SecuritiesSuspension &\; TerminationDifferences between editions 4.1\, 6. 1 and 6.2State Co ntract DataNew Contracts (SSWC &\; DCC)Who Can Attend:Principal Agents and Project ManagersArchitectsQuantity SurveyorsEngineersBuilding Contract ors and SubcontractorsEmployersBuilding Owners\, DevelopersProcurement Off icersProject FinanciersLegal AdvisorsVIRTUAL SEMINAR COST (FOR BOTH SESSIO NS): Single delegate  |  R3 825.00Multiple delegates (2 or more)  |   R3 385.00Session 1: 15 July 2025 01:00 PM   |  Session 2: 16 July 2 025 01:00 PMTime shows in JohannesburgEARN CPD CREDITS!  TOTAL OF 7 HOU RS(Each session: 3 hours and 1 hour for quiz completion)*PLEASE NOTE: Reg ister with the email address that you will use to access the webinar on th e day of the sessions.* REGISTER HERE ATTACH;FMTTYPE=image/jpeg:https://jbcc.co.za/wp-content/uploads/2019/01/se rvices-3-960x600-1.jpeg END:VEVENT BEGIN:VEVENT UID:60@jbcc.co.za DTSTART;TZID=Africa/Johannesburg:20250723T130000 DTEND;TZID=Africa/Johannesburg:20250724T160000 DTSTAMP:20250109T091823Z URL:https://jbcc.co.za/events/nssa-training-23-24-july-2025/ SUMMARY:NSSA TRAINING - 23-24 July 2025 DESCRIPTION:The JBCC is bridging the gap with tailormade training to elevat e subcontractors with skills of administering and understanding JBCC contr acts.\nNEW NSSA TRAINING\nOur aim is to provide a clear overview and under standing of the following topics:\n\n• The Law and its application to Co nstruction\n• The importance of Standard Form Contracts\, with a focus o n the JBCC\n• To successfully complete the NSSA Contract Data\n• To un derstand Preliminaries\n• An update on JBCC publications\n• To have an d understanding of the JBCC N/S Subcontract Agreement with a focus on the following clauses:\n\nAn expert in arbitration and adjudication\, having w orked on more than 65 cases and affiliated with esteemed organizations lik e CAASA\, the Master Builders Association North\, ASAQS\, Brad has countle ss years of experience in building contacts.  He also sits behind numerou s training programs\, having collaborated extensively with IOPSA.\n\nLed b y an industry expert\, this seminar guarantees insights and actionable str ategies to your contract administration skills.\n\nThis is your opportunit y to secure your spot of construction knowledge.\n\nDATES : \n23 July 202 5 : 13:00 - 16:00\n24 July 2025 : 13:00 - 16:00\n\nTime shows in Johannes burg\nSingle delegate : R 1 600.00 incl.\nMultiple delegates: R1 520.00 in cl.\n\nThis is a virtual\, 2 day course.\nClick the link below to reserve your spot:\nREGISTER HERE\nDon't miss out on this opportunity ! Join us fo r a riveting seminar that promises to fuel your success in the constructio n industry.\nTERMS &\; CONDITIONS END:VEVENT BEGIN:VEVENT UID:56@jbcc.co.za DTSTART;TZID=Africa/Johannesburg:20250826T130000 DTEND;TZID=Africa/Johannesburg:20250826T160000 DTSTAMP:20250109T091904Z URL:https://jbcc.co.za/events/extension-of-time-and-role-of-the-principal- agent-webinar-26-august-2025/ SUMMARY:EXTENSION OF TIME AND ROLE OF THE PRINCIPAL AGENT WEBINAR - 26 Aug ust 2025 DESCRIPTION:JBCC MAY 2018 6TH EDITION: CLAUSE 23.0\nGUIDELINES ON HOW TO AD MINISTER EXTENSION OF TIME FOR PRACTICAL COMPLETION\nSESSION 1\nJBCC May 2 018 6th Edition: Clause 23.0 Guidelines on How to Administer Extension of Time for Practical Completion\n\n• Delays where the contractor is not at fault would normally constitute a valid claim for (EOT).\n• Delays affe cts critical path of projects.\n• Confirming a delay and/ or disruption is not an easy task: it is a time-consuming process\, especially in multif aceted projects with thousands of activities\, a lot of details\, as well as the involvement of many stakeholders.\n• It is important for clients\ , contractors\, sub-contractors\, and consultants to understand the fundam ental requirements of compiling a successful EOT claim\, and the adjudicat ion of claims submitted.\n• These training notes will provide those invo lved in the preparation and adjudication of EOT claims under the JBCC with some essential information to deal more productively with this complex ma tter.\n• On larger projects\, the magnitude of time-related costs can ea sily run into millions of rand. With so much at stake\, it is understandab le that delay claims are a major source of disputes in the construction in dustry.\n• The proper assessment of delay claims is essential so that th e parties can deal with it without having to resolve the dispute in expens ive and drawn-out arbitration or litigation processes.\n\nSESSION 2\n\nJBC C MAY 2018 6th Edition: Understanding The Roles of The Various Role Player s Involved in The Building Contract with Emphasis on The Role of The Princ ipal Agent\n\n• The building contract involves a host of role players to establish a successful project - role players all have specific functions to be performed within specific boundaries\, with specific powers entrust ed to them.\n• Role players must work together to ensure a successful pr oject is completed within timeframes and with professionalism\, integrity\ , honesty and moral standards.\n• Some functions are regulated by contra cts between role players\, but others are governed by the standards laid d own by society – the so-called boni mores of a community.\n• Role play ers must be aware of the impact of their actions.\n• It is imperative th at all parties involved in a project have proper detailed knowledge of the ir respective roles\, powers\, duties\, timelines and application of speci alised professional contributions to the “team.”\n• It is the functi on of the principal agent to bring all the aspects\, required for a succes sful building project\, together in a coordinated and orderly manner.\n• The role of the principal agent therefore requires a proper understanding or else a project may fall apart to the detriment of all parties involved .\n• If the role of the principal agent is not fully understood\, chaos may be the result in which all parties suffer financial loss\, impaired re putations and environmental damage.\nVIRTUAL SEMINAR COST : \nSingle dele gate  |  R1 875.00\nMultiple delegates (2 or more)  |  R1 770.00\n \nOne day webinar from 13h00 -16h00\n\nTime shows in Johannesburg\n\nEARN CPD CREDITS!  TOTAL OF 7 HOURS\n(Each session: 3 hours and 1 hour for q uiz completion)\n*PLEASE NOTE: Register with the email address that you w ill use to access the webinar on the day of the sessions.*\n\nREGISTER HER E\n\n ATTACH;FMTTYPE=image/jpeg:https://jbcc.co.za/wp-content/uploads/2019/01/se rvices-3-960x600-1.jpeg END:VEVENT BEGIN:VEVENT UID:67@jbcc.co.za DTSTART;TZID=Africa/Johannesburg:20250910T130000 DTEND;TZID=Africa/Johannesburg:20250911T160000 DTSTAMP:20250109T090954Z URL:https://jbcc.co.za/events/jbcc-agreements-contracts-2018-2020-10-11-se ptember-2025/ SUMMARY:JBCC AGREEMENTS/CONTRACTS 2018/2020 - 10-11 September 2025 DESCRIPTION:This is a training course conducted online using zoom presented in two sessions starting from 13h00 and ends at 16h00Presented by  – G erard Damstra &\; Brad BoertjeObjectives:The interpretation and underst anding of the JBCC agreements and contracts is fundamental in carrying out a successful construction project to final completion stage. Many project s stand still due the lack of contract knowledge in implementation. It is crucial that contracting parties adhere and fully understand the JBCC clau ses before entering a JBCC agreement. This webinar reviews the JBCC clause s from implementation of a project to the final completion stages and give s a view to the delegates the challenges that might be experienced in prog amme stages\, remedies that can be used and what to avoid when administeri ng a project using the JBCC agreements.Learning Outcomes:Describe the deve lopment of the various types of building contracts in use in South Africa\ ;Identify the important role of the JBCC documents in the South African bu ilding industry\;Have an in-depth understanding of the historical backgrou nd and structure of the JBCC May 2018 6.2nd Ed\;Know what the JBCC documen ts comprise of and its application in the South African building industry and elsewhere in Africa\;Know what the duties are of the Principal Agent a rising from the JBCC documents\; andUnderstand the mechanisms and day-to-d ay use of a selection of commonly encountered provisions.SESSION 1Construc tion LawPre-Contract ActivitiesRisk Management Procurement / Contract Data Dispute ResolutionMediationAdjudicationArbitrationDefinitionsOffer and Acc eptance DocumentsAgents/ Design Duties of the PartiesSubcontractorsSESSION 2Contract InstructionsExecution &\; Completion Penalties (Damages)Paym entsAdjustment of the Contract ValueInsurances &\; SecuritiesSuspension &\; TerminationDifferences between editions 4.1\, 6. 1 and 6.2State Co ntract DataNew Contracts (SSWC &\; DCC)Who Can Attend:Principal Agents and Project ManagersArchitectsQuantity SurveyorsEngineersBuilding Contract ors and SubcontractorsEmployersBuilding Owners\, DevelopersProcurement Off icersProject FinanciersLegal AdvisorsVIRTUAL SEMINAR COST (FOR BOTH SESSIO NS): Single delegate  |  R3 825.00Multiple delegates (2 or more)  |   R3 385.00Session 1: 10 September 2025 01:00 PM   |  Session 2: 11 S eptember 2025 01:00 PMTime shows in JohannesburgEARN CPD CREDITS!  TOTA L OF 7 HOURS(Each session: 3 hours and 1 hour for quiz completion)*PLEASE NOTE: Register with the email address that you will use to access the web inar on the day of the sessions.* REGISTER HERE ATTACH;FMTTYPE=image/jpeg:https://jbcc.co.za/wp-content/uploads/2019/01/se rvices-3-960x600-1.jpeg END:VEVENT BEGIN:VTIMEZONE TZID:Africa/Johannesburg X-LIC-LOCATION:Africa/Johannesburg BEGIN:STANDARD DTSTART:20220215T130000 TZOFFSETFROM:+0200 TZOFFSETTO:+0200 TZNAME:SAST END:STANDARD END:VTIMEZONE END:VCALENDAR